﻿|*|EV24001-REV-1|11/06/2025|06:07:46|.|3.5.4.0|
|*|ROBBEN ISLAND MUSEUM - NMG BUILDING REV 01|
COUNTER|ISC|SECTION|BILL|PAGE NO|ITEM NO|DOC REF|PAY REF|DESCRIPTION|UNIT|QUANTITY|RATE|AMOUNT|LABOUR INTENSIVE|WORDING|EDIT DATE
1|18387|1|1|103||1||SECTION NO 1 |H1|0.0|||||20/07/2023 02:08:24|

2|18388|1|1|103||1||BILL NO 1 |H1|0.0|||||20/07/2023 02:08:24|

3|18389|1|1|103||1||PRELIMINARIES|H1|0.0|||||20/07/2023 02:08:24|

4|28184|1|1|103||||BUILDING AGREEMENT AND PRELIMINARIES|H2|0.0|||||20/07/2023 02:15:03|

5|28185|1|1|103||1||The JBCC Principal Building Agreement (Edition 6.2 - May 2018) prepared by the Joint Building Contracts Committee shall be the applicable building agreement, amended as hereinafter described||0.0|||||20/07/2023 02:15:03|

6|28186|1|1|103||||The JBCC Principal Building Agreement contract data form an integral part of this agreement||0.0|||||20/07/2023 02:15:03|

7|28187|1|1|103||1||The JBCC General Preliminaries (May 2018) published by the Joint Building Contracts Committee for use with the JBCC Principal Building Agreement (Edition 6.2 - May 2018) shall be deemed to be incorporated in these bills of quantities, amended as hereinafter described||0.0|||||20/07/2023 02:15:03|

8|28188|1|1|103||1||The contractor is deemed to have referred to the abovementioned documents for the full intent and meaning of each clause||0.0|||||20/07/2023 02:15:04|

9|28189|1|1|103||1||The clauses in the abovementioned documents are hereinafter referred to by clause number and heading only||0.0|||||20/07/2023 02:15:04|

10|28190|1|1|103||1||Where any item is not relevant to this agreement such item is marked N/A signifying "not applicable"||0.0|||||20/07/2023 02:15:04|

11|28191|1|1|103||||Where standard clauses or alternatives are not entirely applicable to this agreement such amendments, modifications, corrections or supplements as will apply are given under each relevant clause heading and such amendments, modifications, corrections or supplements shall take precedence notwithstanding anything to the contrary contained in the abovementioned documents||0.0|||||20/07/2023 02:15:04|

12|28192|1|1|104||||PREAMBLES FOR TRADES|H2|0.0|||||20/07/2023 02:15:04|

13|28193|1|1|104||||The General Preambles for Trades 2017 published by the Association of South African Quantity Surveyors is designed to support and extend the abbreviated descriptions utilised in these bills of quantities by inter alia referring to SANS construction standards. Where such preambles are not applicable (eg where BS or Euro construction standards are applicable or the design consultants provide other preambles/specifications for insertion), users are to ensure that the abbreviated descriptions when read in conjunction with the Standard System of Measuring Building Work (seventh edition) for works within South Africa or the Standard Method of Measuring Building Work for Africa 2015 (first edition) for works elsewhere in Africa, represent the full description by extending the abbreviated bills of quantities descriptions and/or by inserting appropriate preambles or specifications||0.0|||||20/07/2023 02:15:04|

14|28194|1|1|104||||Note that the text of the Standard System of Measuring Building Work (seventh edition) and that of the Standard Method of Measuring Building Work for Africa 2015 (first edition) is the same||0.0|||||20/07/2023 02:15:04|

15|28195|1|1|104||||The latest version of the General Preambles for Trades should be referred to should the General Preambles for Trades 2017 be revised in future||0.0|||||20/07/2023 02:15:04|

16|28196|1|1|104||||The General Preambles for Trades 2017 published by the Association of South African Quantity Surveyors shall be deemed to be incorporated in these bills of quantities and no claims arising from brevity of description of items fully described in the said General Preambles will be entertained||0.0|||||20/07/2023 02:15:04|

17|28197|1|1|104||||Supplementary preambles and/or specifications are incorporated in these bills of quantities to satisfy the requirements of this project. Such supplementary preambles and/or specifications shall take precedence over the provisions of the General Preambles||0.0|||||20/07/2023 02:15:04|

18|28198|1|1|104||||The contractor's prices for all items throughout these bills of quantities shall take account of and include where applicable for all of the obligations, requirements and specifications given in the General Preambles and in any supplementary preambles and/or specifications||0.0|||||20/07/2023 02:15:04|

19|28199|1|1|105||||STRUCTURE OF THIS PRELIMINARIES BILL|H2|0.0|||||20/07/2023 02:15:04|

20|28200|1|1|105||||Section A :  A recital of the headings of the individual clauses in the aforementioned JBCC Principal Building Agreement||0.0|||||20/07/2023 02:15:04|

21|28201|1|1|105||||Section B :  A recital of the headings of the individual clauses in the aforementioned JBCC General Preliminaries||0.0|||||20/07/2023 02:15:04|

22|28202|1|1|105||||Section C : Any special clauses to meet the particular circumstances of the project||0.0|||||20/07/2023 02:15:04|

23|28203|1|1|105||||PRICING OF PRELIMINARIES|H2|0.0|||||20/07/2023 02:15:04|

24|28204|1|1|105||||Should the contractor select Option A in the contract data for the adjustment of preliminaries, the amounts entered against the relevant items in these preliminaries are to be divided into one or more of the three categories provided namely fixed (F), value related (V) and time related (T) ||0.0|||||20/07/2023 02:15:04|

25|28205|1|1|105||2||SECTION A: PRINCIPAL BUILDING AGREEMENT|H2|0.0|||||20/07/2023 02:15:04|

26|28206|1|1|105||2||Interpretation (A1-A7)|H3|0.0|||||20/07/2023 02:15:04|

27|28207|1|1|105| A|2.1||Clause 1.0 - Definitions and interpretation|CONT|0.00|||||20/07/2023 02:15:04|

28|28208|1|1|105||||Pricing of bills of quantities|CONT|0.0|||||20/07/2023 02:15:04|

29|28209|1|1|105||||The contractor is to allow opposite each item for all costs in connection therewith. All prices to include, unless otherwise stated, for all materials, fabrication, conveyance and delivery, unloading, storing, unpacking, hoisting, labour, setting, fitting and fixing in position, cutting and waste (except where to be measured in accordance with the standard system of measurement), patterns, models and templates, plant, temporary works, returning of packaging, duties, taxes (other than Value Added Tax), imposts, establishment charges, overheads, profit and all other obligations arising out of this agreement. Value Added Tax (VAT) is to be separately stated on the summary page of these bills of quantities|CONT|0.0|||||20/07/2023 02:15:04|

30|28210|1|1|106||||Items left unpriced will be deemed to be covered in prices against other items throughout these bills of quantities and no claim for any extras arising out of the contractor's omission to price any item will be entertained|CONT|0.0|||||20/07/2023 02:15:04|

31|28211|1|1|106||||Prices for all construction equipment, temporary works, services and other items shall include for the supply, maintenance, operating cost and subsequent removal and making good as necessary|CONT|0.0|||||20/07/2023 02:15:04|

32|28212|1|1|106||||Abbreviated descriptions|CONT|0.0|||||20/07/2023 02:15:04|

33|28213|1|1|106||||The items in these bills of quantities utilise abbreviated descriptions. It is the intention that the abbreviated descriptions be fully described when read with the applicable measuring system and the relevant preambles and/or specifications. However, should the full intent and meaning of any description not be clear, the contractor shall, before submission of his tender, call for a written directive from the principal agent, failing which it shall be assumed that the contractor has allowed in his pricing for materials and workmanship in terms of international best practice|CONT|0.0|||||20/07/2023 02:15:04|

34|28214|1|1|106||||Legal status of contractor|CONT|0.0|||||20/07/2023 02:15:05|

35|28215|1|1|106| A|||If the contractor constitutes a joint venture, consortium or other unincorporated grouping of two or more persons then:|CONT|0.0|||||20/07/2023 02:15:05|

36|28216|1|1|106||||1.   These persons are deemed to be jointly and severally liable to the employer for the performance of this agreement|CONT|0.0|||||20/07/2023 02:15:05|

37|28217|1|1|106||||2.   These persons shall notify the employer of their leader who has assigned authority to bind the contractor and each of these persons                                                                                                                                          |CONT|0.0|||||20/07/2023 02:15:05|

38|28218|1|1|106||||3.  The contractor shall not alter its composition or legal status without the prior written consent of the employer|CONT|0.00|||||20/07/2023 02:15:05|

39|28219|1|1|106||||F:............................. V:............................ T:............................|Item|1.00|||||19/11/2024 04:47:43|

40|28221|1|1|107| A|2.1||Clause 2.0 - Law, regulations and notices|CONT|0.00|||||20/07/2023 02:15:05|

41|28222|1|1|107||||F:............................. V:............................ T:............................|Item|1.00|||||13/05/2024 12:04:06|

42|28223|1|1|107| B|2.2||Clause 3.0 - Offer and acceptance  F:............................. V:............................ T:............................ |Item|1.00|||||20/07/2023 02:15:05|

43|28224|1|1|107| C|||Clause 4.0 - Cession and assignment  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:05|

44|28225|1|1|107| D|||Clause 5.0 - Documents|CONT|0.00|||||20/07/2023 02:15:05|

45|28226|1|1|107||||Value Added Tax|CONT|0.0|||||20/07/2023 02:15:05|

46|28227|1|1|107||||Provision is made in the summary page of these bills of quantities for the inclusion of Value Added Tax (VAT)|CONT|0.0|||||20/07/2023 02:15:05|

47|28228|1|1|107||||Priced document as specification Clause 5.4 is applicable|CONT|0.0|||||20/07/2023 02:15:05|

48|28229|1|1|107||||The principal agent shall decide which portion of the priced document may be used as a specification of materials and goods or methods, if any.|CONT|0.0|||||20/07/2023 02:15:05|

49|28230|1|1|107||||Electronic issue of drawings  All drawings for this project will be issued electronically and the contractor shall be deemed to have received such drawings on the date that such drawings have been dispatched electronically [5.6]  It is the responsibility of the contractor to allow for an on-site printer and to ensure that hard copies of the latest construction drawings and information are printed timeously and kept on site as soon as the contractor has received the electronically issued drawings and information.|CONT|0.0|||||20/07/2023 02:15:05|

50|28231|1|1|107||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:05|

51|28232|1|1|108| A|||Clause 6.0 - Employer's agents|CONT|0.00|||||20/07/2023 02:15:05|

52|28233|1|1|108||||Delegated authority|CONT|0.0|||||20/07/2023 02:15:05|

53|28234|1|1|108||8||The authority of the principal agent to issue contract instructions [17.1] and perform duties for specific aspects of the works is delegated to agents as follows [6.2]. This does not preclude the principal agent from issuing such contract instructions:|CONT|0.0|||||20/07/2023 02:15:05|

54|28235|1|1|108||8||1. Architect|CONT|0.0|||||20/07/2023 02:15:05|

55|28236|1|1|108||||Note that the contract instructions hereinafter are selected from those listed in clause 17.1 of the JBCC PBA|CONT|0.0|||||20/07/2023 02:15:05|

56|28237|1|1|108||8||1.1 Duties [6.2] :  The architect is responsible for the architectural design, functional design and quality inspection of the works|CONT|0.0|||||20/07/2023 02:15:05|

57|28238|1|1|108||||1.2 Contract instructions [6.2; 17.1] :|CONT|0.0|||||20/07/2023 02:15:05|

58|28239|1|1|108||9||1.2.1     Rectification of discrepancies, errors in description or quantity or omission of items in the agreement other than in the JBCC Principal Building Agreement |CONT|0.0|||||20/07/2023 02:15:05|

59|28240|1|1|108||9||1.2.2     Alteration to design, standards or quantity of the works provided that such contract instructions shall not substantially change the scope of the works|CONT|0.0|||||20/07/2023 02:15:06|

60|28241|1|1|108||9||1.2.3     The site [13.0]|CONT|0.0|||||20/07/2023 02:15:06|

61|28242|1|1|108||9||1.2.4     Compliance with the law, regulations and bylaws [2.1]|CONT|0.0|||||20/07/2023 02:15:06|

62|28243|1|1|108||9||1.2.5     Provision and testing of samples of materials and goods and/or of finishes and assemblies of elements of the works |CONT|0.0|||||20/07/2023 02:15:06|

63|28244|1|1|108||9||1.2.6     Opening up of work for inspection, removal or re-execution [23.2.4; 26.4.2]|CONT|0.0|||||20/07/2023 02:15:06|

64|28245|1|1|108||9||1.2.7     Removal or re-execution of work|CONT|0.0|||||20/07/2023 02:15:06|

65|28246|1|1|109||9||1.2.8     Removal or substitution of any materials and goods|CONT|0.0|||||20/07/2023 02:15:06|

66|28247|1|1|109||9||1.2.9     Protection of the works|CONT|0.0|||||20/07/2023 02:15:06|

67|28248|1|1|109||9||1.2.10   Making good physical loss and repairing damage to the works [23.2.2]|CONT|0.0|||||20/07/2023 02:15:06|

68|28249|1|1|109||9||1.2.11   Rectification of defects [21.2]|CONT|0.0|||||20/07/2023 02:15:06|

69|28250|1|1|109||9||1.2.12    A list for practical completion specifying outstanding or defective              work to be rectified to achieve practical completion, a list for             completion and a list for final completion specifying outstanding or             defective work to be rectified to achieve final completion|CONT|0.0|||||20/07/2023 02:15:06|

70|28251|1|1|109||9||1.2.13   Expenditure of budgetary allowances, prime cost amounts and             provisional sums|CONT|0.0|||||20/07/2023 02:15:06|

71|28252|1|1|109||10||1.2.14    Appointment of a subcontractor [14.0; 15.0]|CONT|0.0|||||20/07/2023 02:15:06|

72|28253|1|1|109||10||1.2.15	 Work by direct contractors [16.0]|CONT|0.0|||||20/07/2023 02:15:06|

73|28254|1|1|109||10||1.2.16   On suspension or termination, protection of the works, removal of             construction equipment and surplus materials and goods [29.0]|CONT|0.0|||||20/07/2023 02:15:06|

74|28255|1|1|109||10||2. Quantity surveyor|CONT|0.0|||||20/07/2023 02:15:06|

75|28256|1|1|109||10||2.1 Duties [6.2] :  The quantity surveyor is responsible for all measurements, valuations, financial assessments and all other quantity surveying and cost control functions of the works|CONT|0.0|||||20/07/2023 02:15:06|

76|28257|1|1|109||||2.2 Contract instructions [6.2; 17.1] :|CONT|0.0|||||20/07/2023 02:15:06|

77|28258|1|1|109||||2.2.1 No contract instructions delegated to the Quantity surveyor|CONT|0.0|||||20/07/2023 02:15:06|

78|28260|1|1|110||12||3. Civil and structural engineer|CONT|0.0|||||20/07/2023 02:15:06|

79|28261|1|1|110||||Note that the contract instructions hereinafter are selected from those listed in clause 17.1 of the JBCC PBA|CONT|0.0|||||20/07/2023 02:15:06|

80|28262|1|1|110||12||3.1 Duties [6.2] :  The civil and structural engineer is responsible for all aspects of civil and structural engineering design and quality inspection of the works|CONT|0.0|||||20/07/2023 02:15:06|

81|28263|1|1|110||||3.2 Contract instructions [6.2; 17.1] :|CONT|0.0|||||20/07/2023 02:15:06|

82|28264|1|1|110||9||3.2.1	Rectification of discrepancies, errors in description or quantity or omission of items in the agreement other than in the JBCC Principal Building Agreement |CONT|0.0|||||20/07/2023 02:15:06|

83|28265|1|1|110||9||3.2.2	Alteration to design, standards or quantity of the works provided that such contract instructions shall not substantially change the scope of the works|CONT|0.0|||||20/07/2023 02:15:06|

84|28266|1|1|110||9||3.2.3	The site [13.0]|CONT|0.0|||||20/07/2023 02:15:06|

85|28267|1|1|110||9||3.2.4 Compliance with the law, regulations and bylaws [2.1]|CONT|0.0|||||20/07/2023 02:15:07|

86|28268|1|1|110||9||3.2.5	Provision and testing of samples of materials and goods and/or of finishes and assemblies of elements of the works|CONT|0.0|||||20/07/2023 02:15:07|

87|28269|1|1|110||9||3.2.6	Opening up of work for inspection, removal or re-execution [23.2.4; 26.4.2]|CONT|0.0|||||20/07/2023 02:15:07|

88|28270|1|1|110||9||3.2.7	Removal or re-execution of work|CONT|0.0|||||20/07/2023 02:15:07|

89|28271|1|1|110||9||3.2.8	Removal or substitution of any materials   	and goods|CONT|0.0|||||20/07/2023 02:15:07|

90|28272|1|1|110||9||3.2.9	Protection of the works|CONT|0.0|||||20/07/2023 02:15:07|

91|28273|1|1|110||9||3.2.10	Making good physical loss and repairing damage to the works [23.2.2]|CONT|0.0|||||20/07/2023 02:15:07|

92|28274|1|1|110||9||3.2.11	Rectification of defects [21.2]|CONT|0.0|||||20/07/2023 02:15:07|

93|28275|1|1|111||9||3.2.12	A list for practical completion specifying outstanding or defective work to be rectified to achieve practical completion, a list for completion and a list for final completion specifying outstanding or defective work to be rectified to achieve final completion|CONT|0.0|||||20/07/2023 02:15:07|

94|28276|1|1|111||9||3.2.13	Expenditure of budgetary allowances, prime cost amounts and provisional sums|CONT|0.0|||||20/07/2023 02:15:07|

95|28277|1|1|111||14||4. Mechanical engineer|CONT|0.0|||||20/07/2023 02:15:07|

96|28278|1|1|111||||Note that the contract instructions hereinafter are selected from those listed in clause 17.1 of the JBCC PBA|CONT|0.0|||||20/07/2023 02:15:07|

97|28279|1|1|111||14||4.1 Duties [6.2] :  The mechanical engineer is responsible for all aspects of mechanical engineering design and quality inspection of the works and, where appointed by the employer for quantity surveying services in respect of the mechanical installations, for all measurements, valuations, financial assessments and all other quantity surveying and cost control functions|CONT|0.0|||||20/07/2023 02:15:07|

98|28280|1|1|111||||4.2 Contract instructions [6.2; 17.1] :|CONT|0.0|||||20/07/2023 02:15:07|

99|28281|1|1|111||9||4.2.1	Rectification of discrepancies, errors in description or quantity or omission of items in the agreement other than in the JBCC Principal Building Agreement |CONT|0.0|||||20/07/2023 02:15:07|

100|28282|1|1|111||9||4.2.2	Alteration to design, standards or quantity of the works provided that such contract instructions shall not substantially change the scope of the works|CONT|0.0|||||20/07/2023 02:15:07|

101|28283|1|1|111||9||4.2.3	Compliance with the law, regulations and bylaws [2.1]|CONT|0.0|||||20/07/2023 02:15:07|

102|28284|1|1|111||9||4.2.4	Provision and testing of samples of materials and goods and/or of finishes and assemblies of elements of the works|CONT|0.0|||||20/07/2023 02:15:07|

103|28285|1|1|111||9||4.2.5	Opening up of work for inspection, removal or re-execution [23.2.4; 26.4.2]|CONT|0.0|||||20/07/2023 02:15:07|

104|28286|1|1|112||9||4.2.6	Removal or re-execution of work|CONT|0.0|||||20/07/2023 02:15:07|

105|28287|1|1|112||9||4.2.7	Removal or substitution of any materials 	and goods|CONT|0.0|||||20/07/2023 02:15:07|

106|28288|1|1|112||9||4.2.8	Protection of the works|CONT|0.0|||||20/07/2023 02:15:07|

107|28289|1|1|112||9||4.2.9	Making good physical loss and repairing damage to the works [23.2.2]|CONT|0.0|||||20/07/2023 02:15:07|

108|28290|1|1|112||9||4.2.10	Rectification of defects [21.2]|CONT|0.0|||||20/07/2023 02:15:07|

109|28291|1|1|112||9||4.2.11	A list for practical completion specifying outstanding or defective work to be  rectified to achieve practical completion, a list for completion and a list for final completion specifying outstanding or defective work to be rectified to achieve final completion|CONT|0.0|||||20/07/2023 02:15:07|

110|28292|1|1|112||9||4.2.12	Expenditure of budgetary allowances, prime cost amounts and provisional sums|CONT|0.0|||||20/07/2023 02:15:07|

111|28293|1|1|112||15||5. Electrical engineer|CONT|0.0|||||20/07/2023 02:15:07|

112|28294|1|1|112||||Note that the contract instructions hereinafter are selected from those listed in clause 17.1 of the JBCC PBA|CONT|0.0|||||20/07/2023 02:15:08|

113|28295|1|1|112||15||5.1 Duties [6.2] :  The electrical engineer is responsible for all aspects of electrical engineering design and quality inspection of the works and, where appointed by the employer for quantity surveying services in respect of the electrical installations, for all measurements, valuations, financial assessments and all other quantity surveying and cost control functions|CONT|0.0|||||20/07/2023 02:15:08|

114|28296|1|1|112||||5.2 Contract instructions [6.2; 17.1] :|CONT|0.0|||||20/07/2023 02:15:08|

115|28297|1|1|112||9||5.2.1	Rectification of discrepancies, errors in description or quantity or omission of items in the agreement other than in the JBCC Principal Building Agreement |CONT|0.0|||||20/07/2023 02:15:08|

116|28298|1|1|113||9||5.2.2	Alteration to design, standards or quantity of the works provided that such contract instructions shall not substantially change the scope of the works|CONT|0.0|||||20/07/2023 02:15:08|

117|28299|1|1|113||9||5.2.3	Compliance with the law, regulations and 	bylaws [2.1]|CONT|0.0|||||20/07/2023 02:15:08|

118|28300|1|1|113||9||5.2.4	Provision and testing of samples of materials and goods and/or of finishes and assemblies of elements of the works|CONT|0.0|||||20/07/2023 02:15:08|

119|28301|1|1|113||9||5.2.5	Opening up of work for inspection, removal or re-execution [23.2.4; 26.4.2]|CONT|0.0|||||20/07/2023 02:15:08|

120|28302|1|1|113||9||5.2.6	Removal or re-execution of work|CONT|0.0|||||20/07/2023 02:15:08|

121|28303|1|1|113||9||5.2.7	Removal or substitution of any materials 	and goods|CONT|0.0|||||20/07/2023 02:15:08|

122|28304|1|1|113||9||5.2.8	Protection of the works|CONT|0.0|||||20/07/2023 02:15:08|

123|28305|1|1|113||9||5.2.9	Making good physical loss and repairing damage to the works [23.2.2]|CONT|0.0|||||20/07/2023 02:15:08|

124|28306|1|1|113||9||5.2.10	Rectification of defects [21.2]|CONT|0.0|||||20/07/2023 02:15:08|

125|28307|1|1|113||9||5.2.11	A list for practical completion specifying outstanding or defective work to be rectified to achieve practical completion, a list for completion and a list for final completion specifying outstanding or defective work to be rectified to achieve final completion|CONT|0.0|||||20/07/2023 02:15:08|

126|28308|1|1|113||9||5.2.12	Expenditure of budgetary allowances, prime cost amounts and provisional sums|CONT|0.0|||||20/07/2023 02:15:08|

127|28309|1|1|113||18||6 Fire consultant|CONT|0.0|||||20/07/2023 02:15:08|

128|28310|1|1|113||||Note that the contract instructions hereinafter are selected from those listed in clause 17.1 of the JBCC PBA|CONT|0.0|||||20/07/2023 02:15:08|

129|28311|1|1|113||18||6.1 Duties [6.2] :  The fire consultant is responsible for all aspects of rational fire design and quality inspection of the works|CONT|0.0|||||20/07/2023 02:15:08|

130|28312|1|1|114||||6.2 Contract instructions [6.2; 17.1] :|CONT|0.0|||||20/07/2023 02:15:08|

131|28313|1|1|114||9||6.2.1	Rectification of discrepancies, errors in description or quantity or omission of items in the agreement other than in the JBCC Principal Building Agreement |CONT|0.0|||||20/07/2023 02:15:08|

132|28314|1|1|114||9||6.2.2	Alteration to design, standards or quantity of the works provided that such contract instructions shall not substantially change the scope of the works|CONT|0.0|||||20/07/2023 02:15:08|

133|28315|1|1|114||9||6.2.3	Compliance with the law, regulations and 	bylaws [2.1]|CONT|0.0|||||20/07/2023 02:15:08|

134|28316|1|1|114||9||6.2.4	Provision and testing of samples of materials and goods  and/or of finishes and assemblies of elements of the works|CONT|0.0|||||20/07/2023 02:15:08|

135|28317|1|1|114||9||6.2.5	Opening up of work for inspection, removal or re-execution [23.2.4; 26.4.2]|CONT|0.0|||||20/07/2023 02:15:08|

136|28318|1|1|114||9||6.2.6	Removal or re-execution of work|CONT|0.0|||||20/07/2023 02:15:08|

137|28319|1|1|114||9||6.2.7	Removal or substitution of any materials 	and goods|CONT|0.0|||||20/07/2023 02:15:08|

138|28320|1|1|114||9||6.2.8	Protection of the works|CONT|0.0|||||20/07/2023 02:15:09|

139|28321|1|1|114||9||6.2.9	Making good physical loss and repairing damage to the works [23.2.2]|CONT|0.0|||||20/07/2023 02:15:09|

140|28322|1|1|114||9||6.2.10	Rectification of defects [21.2]|CONT|0.0|||||20/07/2023 02:15:09|

141|28323|1|1|114||9||6.2.11	A list for practical completion specifying outstanding or defective work to be rectified to achieve practical completion, a list for completion and a list for final completion specifying outstanding or defective work to be rectified to achieve final completion|CONT|0.0|||||20/07/2023 02:15:09|

142|28324|1|1|114||9||6.2.12	Expenditure of budgetary allowances, prime cost amounts and provisional sums|CONT|0.0|||||20/07/2023 02:15:09|

143|28326|1|1|115||20||7. Health and safety consultant|CONT|0.0|||||20/07/2023 02:15:09|

144|28327|1|1|115||20||7.1 Duties [6.2] :  The health and safety consultant is responsible for all aspects of health and safety of the works. Without derogating from the generality thereof, the health and safety consultant will perform the following specific functions and duties in respect of the health and safety aspects of the works. He shall:|CONT|0.00|||||20/07/2023 02:15:09|

145|28328|1|1|115||20||7.1.1	Act as the employer's agent in terms of the Construction Regulations issued in terms of the Occupational Health and Safety Act,1993 as amended|CONT|0.0|||||20/07/2023 02:15:09|

146|28329|1|1|115||20||7.1.2	Prepare and update the health and safety 	specification for the works|CONT|0.0|||||20/07/2023 02:15:09|

147|28330|1|1|115||20||7.1.3	Agree with the contractor the health and 	safety plan for the works|CONT|0.0|||||20/07/2023 02:15:09|

148|28331|1|1|115||20||7.1.4	Carry out regular audits to ensure adherence to the safety plan and compliance with the act and regulations|CONT|0.00|||||20/07/2023 02:15:09|

149|28332|1|1|115||20||7.1.5	Stop the execution of the works where the agreed specification or plan is not adhered to|CONT|0.00|||||20/07/2023 02:15:09|

150|28333|1|1|115||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:09|

151|28334|1|1|115| A|||Clause 7.0 - Design responsibility  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:09|

152|28335|1|1|115||2||Insurances and securities (A8-A11)|H3|0.0|||||20/07/2023 02:15:09|

153|28336|1|1|115| B|||Clause 8.0 - Works risk  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:09|

154|28337|1|1|116| A|||Clause 9.0 - Indemnities  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:09|

155|28338|1|1|116| B|||Clause 10.0 - Insurances  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:14:30|

156|28339|1|1|116| C|||Clause 11.0 - Securities|CONT|0.00|||||20/07/2023 02:15:09|

157|28340|1|1|116| D|||Guarantee for payment|N/A|0.0|||||20/07/2023 02:15:09|

158|28341|1|1|116| E|||The employer shall provide to the contractor a guarantee for payment in the amount of .......................................................Rand (R...........................) [11.5.1].  The contractor shall consequently waive his lien or right of continuing possession of the works [11.10]|N/A|0.0|||||20/07/2023 02:15:09|

159|28342|1|1|116| F|||Extension of waiver of lien|N/A|0.0|||||20/07/2023 02:15:09|

160|28343|1|1|116| G|||The contractor shall ensure that a waiver of lien is included in all subcontracts and that the works executed on the site are kept free of all liens and other encumbrances at all times [11.10]|N/A|0.0|||||20/07/2023 02:15:09|

161|28344|1|1|116||||F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:14:39|

162|28345|1|1|116||3||Execution (A12 - A17) |H3|0.0|||||20/07/2023 02:15:10|

163|28346|1|1|116| H|3.15||Clause 12.0 - Obligations of the parties|CONT|0.00|||||20/07/2023 02:15:10|

164|28347|1|1|116||||Office accommodation  The contractor shall provide, maintain and remove on practical completion air conditioned office accommodation with suitable tables and chairs for meetings to be held on the site. Such offices shall be kept clean and fit for use at all times [12.2.18]|CONT|0.0|||||20/07/2023 02:15:10|

165|28348|1|1|117|||| Notice board  The contractor shall erect in a position approved by the principal agent, maintain and remove on practical completion a notice board recommended by the South African Institute of Architects and as approved by the principal agent listing the names and logos of the employer, the contractor and the professional consultants. No subcontractor or supplier notice boards may be erected unless permission is granted by the principal agent for such notice boards to be erected [12.2.18]|CONT|0.0|||||20/07/2023 02:15:10|

166|28349|1|1|117||||Statutory and other notices|CONT|0.0|||||20/07/2023 02:15:10|

167|28350|1|1|117||||The contractor shall submit and/or comply with all statutory and other notices that may be required by any local or other authority in order not to cause any delay to the commencement of the works by the contractor. The contractor shall pay all deposits or fees in this regard|CONT|0.0|||||20/07/2023 02:15:10|

168|28351|1|1|117||||It is, however, specifically recorded that the employer shall be responsible for the timeous approval of building plans by any local or other authorities and the payment of any fees or charges related thereto|CONT|0.0|||||20/07/2023 02:15:10|

169|28352|1|1|117||||F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:14:47|

170|28353|1|1|117| A|3.16||Clause 13.0 - Setting out  F:............................. V:............................ T:............................|Item|1.00|||||24/07/2023 10:31:18|

171|28354|1|1|117| B|3.20||Clause 14.0 - Nominated subcontractors|CONT|0.00|||||20/07/2023 02:15:10|

172|28355|1|1|117| C|||F:............................. V:............................ T:............................|Item|1.00|||||12/11/2024 10:55:46|

173|28356|1|1|117| D|3.20||Clause 15.0 - Selected subcontractors|CONT|0.00|||||20/07/2023 02:15:10|

174|28357|1|1|117||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:10|

175|28358|1|1|118| A|||Clause 16.0 - Direct contractors  Attendance on direct contractors  In respect of direct contractors the contractor shall:|CONT|0.0|||||20/07/2023 02:15:10|

176|28359|1|1|118||||1.   Designate an area for the direct contractor to establish a temporary office and workshop and storage of equipment and materials|CONT|0.0|||||20/07/2023 02:15:10|

177|28360|1|1|118||||2.	Allow the use of personnel welfare facilities, where provided|CONT|0.0|||||20/07/2023 02:15:10|

178|28361|1|1|118||||3.   Provide water, lighting and single phase electric power to a position within 50m of the place where the direct contract work is to be carried out, other than fuel or power for commissioning of any installation|CONT|0.0|||||20/07/2023 02:15:10|

179|28362|1|1|118||||4.   Permit the direct contractor to use erected scaffolding, hoisting facilities, etc provided by the contractor, in common with others having the like right, while it remains erected on the site [16.1]|CONT|0.0|||||20/07/2023 02:15:10|

180|28363|1|1|118||3.20||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:10|

181|28364|1|1|118| B|3.17||Clause 17.0 - Contract instructions  Site instructions  Instructions issued on site are to be recorded in a site instruction book which is to be supplied and maintained on site by the contractor|CONT|0.00|||||20/07/2023 02:15:10|

182|28365|1|1|118||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:10|

183|28366|1|1|118||4||Completion (A18 - A24) |H3|0.0|||||20/07/2023 02:15:10|

184|28367|1|1|118| C|3.18||Clause 18.0 - Interim completion|Item|1.00|||||15/07/2024 04:24:06|

185|28368|1|1|118| D|3.19||Clause 19.0 - Practical completion  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:10|

186|28369|1|1|119| A|3.20||Clause 20.0 - Completion in sections |CONT|0.00|||||20/07/2023 02:15:10|

187|28370|1|1|119||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:10|

188|28371|1|1|119| B|4.21||Clause 21.0 - Defects liability period and final completion|CONT|0.00|||||20/07/2023 02:15:11|

189|28372|1|1|119||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

190|28373|1|1|119| C|4.22||Clause 22.0 - Latent defects liability period F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

191|28374|1|1|119| D|4.23||Clause 23.0 - Revision of the date for practical completion  Substitution of materials and goods  The removal or substitution of any materials and goods which do not conform to the specification or the contract drawings shall not constitute grounds for the extension of the construction period nor for the adjustment of the contract value [17.1.8; 23.1 & 2]|CONT|0.00|||||20/07/2023 02:15:11|

192|28375|1|1|119||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

193|28376|1|1|119| E|4.24||Clause 24.0 - Penalty for late or non-completion  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

194|28378|1|1|119||4||Payment (A25 - A27) |H3|0.0|||||20/07/2023 02:15:11|

195|28379|1|1|119| F|4.25||Clause 25.0 - Payment|CONT|0.00|||||20/07/2023 02:15:11|

196|28380|1|1|120||5.32||Prices submitted  Where prices are submitted by the contractor or subcontractor during the progress of the works in respect of contract instructions or in regard to a claim under the terms of this agreement and notwithstanding the fact that such prices may be used in an interim payment certificate, there is to be no presumption of acceptance. Should the principal agent wish to accept any such prices prior to the issue of the certificate of final completion, it shall be in writing|CONT|0.00|||||20/07/2023 02:15:11|

197|28381|1|1|120||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

198|28382|1|1|120| A|4.26||Clause 26.0 - Adjustment of the contract value and final account|CONT|0.00|||||20/07/2023 02:15:11|

199|28383|1|1|120||||Fluctuations in costs  All fluctuations in costs, with the exception of fluctuations in the rate of Value Added Tax, shall be for the account of the contractor [26.9.5]|CONT|0.0|||||20/07/2023 02:15:11|

200|28384|1|1|120||||Tenant installation/user requirements delayed  There is a possibility that certain works related to tenant installation/user requirements may have to be delayed and may consequently not be executed prior to practical completion|CONT|0.0|||||20/07/2023 02:15:11|

201|28385|1|1|120||||Should the contractor be instructed to do so he shall execute this work under the conditions pertaining to this agreement on the basis that a separate amount for preliminaries appurtenant to this work (if applicable) is agreed to between the contractor and the principal agent and on condition that instruction to proceed with such work is given to him within a period of three (3) calendar months after the date of practical completion of the works|CONT|0.00|||||20/07/2023 02:15:11|

202|28386|1|1|120||||The employer reserves the right to omit such work without compensation to the contractor for loss of profit or any other loss which the contractor may suffer as a result of such omission|CONT|0.0|||||20/07/2023 02:15:11|

203|28387|1|1|121||||Cost of claims  All costs incurred by the contractor in the preparation of claims shall be borne by the contractor. This provision shall not preclude an adjudicator or an arbitrator appointed in terms of this agreement [30.6 & 7] from making a determination on costs|CONT|0.00|||||20/07/2023 02:15:11|

204|28388|1|1|121||||Claims from subcontractors The contractor shall review, assess and adjudicate any claims received by him from any subcontractor and thereafter submit same to the principal agent with a recommendation in order to assist the principal agent in adjudicating the claim [26.6]|CONT|0.00|||||20/07/2023 02:15:11|

205|28389|1|1|121||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

206|28390|1|1|121| A|4.27||Clause 27.0 - Recovery of expense and/or loss  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

207|28391|1|1|121||5||Suspension and termination (A28 - A29) |H3|0.0|||||20/07/2023 02:15:11|

208|28392|1|1|121| B|4.28||Clause 28.0 - Suspension by the contractor |CONT|0.00|||||20/07/2023 02:15:11|

209|28393|1|1|121||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

210|28394|1|1|121| C|4.29||Clause 29.0 - Termination|CONT|0.00|||||20/07/2023 02:15:11|

211|28395|1|1|121||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:11|

212|28396|1|1|121||6||Dispute resolution (A30) |H3|0.0|||||20/07/2023 02:15:12|

213|28397|1|1|121| D|4.30||Clause 30.0 - Dispute resolution  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

214|28398|1|1|122| A|6||Agreement|CONT|0.0|||||20/07/2023 02:15:12|

215|28399|1|1|122||||The required information of the parties and the amount of the contract sum shall be inserted in the agreement for signature of the agreement by the parties  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

216|28400|1|1|122| B|6||Contract data|CONT|0.0|||||20/07/2023 02:15:12|

217|28401|1|1|122||||Tenderer's selections|CONT|0.0|||||20/07/2023 02:15:12|

218|28402|1|1|122||||Before submission of his tender the contractor is to complete the tenderer's selections in the contract data|CONT|0.0|||||20/07/2023 02:15:12|

219|28403|1|1|122||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

220|28404|1|1|122||9||SECTION B:  GENERAL PRELIMINARIES |H2|0.0|||||20/07/2023 02:15:12|

221|28405|1|1|122||9||Definitions and interpretation (B1) |H3|0.0|||||20/07/2023 02:15:12|

222|28406|1|1|122| C|9.45||Clause 1.1 - Definitions  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

223|28407|1|1|122| D|9.45||Clause 1.2 - Interpretation  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

224|28408|1|1|122||9||Documents (B2) |H3|0.0|||||20/07/2023 02:15:12|

225|28409|1|1|122| E|9.46||Clause 2.1 - Checking of documents  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

226|28410|1|1|122| F|9.47||Clause 2.2 - Provisional bills of quantities  F:............................. V:............................ T:............................|Item|1.00|||||24/07/2023 10:31:35|

227|28411|1|1|123| A||| Multiple procurement  These bills of quantities are in multiple procurement format ie the "wet trades" - earthworks, concrete, formwork and reinforcement, precast concrete, masonry, waterproofing and sub-surface drainage - are provisionally measured and the subsequent trades are budgetary allowances and/or provisional sums  F:............................. V:............................ T:............................|N/A|0.0|||||20/07/2023 02:15:12|

228|28412|1|1|123| B|9.48||Clause 2.3 - Availability of construction information|CONT|0.0|||||20/07/2023 02:15:12|

229|28413|1|1|123||||F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

230|28414|1|1|123| C|9.48||Clause 2.4 - Ordering of materials and goods  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

231|28415|1|1|123||10||Previous work and adjoining properties (B3) |H3|0.0|||||20/07/2023 02:15:12|

232|28416|1|1|123| D|||Clause 3.1 - Previous work - dimensional accuracy  F:............................. V:............................ T:............................|Item|1.00|||||12/11/2024 10:56:14|

233|28417|1|1|123| E|||Clause 3.2 - Previous work - defects  F:............................. V:............................ T:............................|Item|1.00|||||12/11/2024 10:56:28|

234|28418|1|1|123| F|||Clause 3.3 - Inspection of adjoining properties  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

235|28419|1|1|123||11||The site (B4) |H3|0.0|||||20/07/2023 02:15:12|

236|28420|1|1|123| G|11.70||Clause 4.1 - Handover of site in stages  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:12|

237|28421|1|1|124| A|11.71||Clause 4.2 - Enclosure of the works  F:............................. V:............................ T:............................|Item|1.00|||||24/07/2023 10:31:45|

238|28422|1|1|124| B|||Clause 4.3 - Geotechnical and other investigations  F:............................. V:............................ T:............................|Item|1.00|||||12/11/2024 10:56:50|

239|28423|1|1|124| C|11.70||Clause 4.4 - Encroachments  F:............................. V:............................ T:............................|Item|1.00|||||12/11/2024 10:56:55|

240|28424|1|1|124| D|11.71||Clause 4.5 - Existing premises occupied  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

241|28425|1|1|124| E|11.72||Clause 4.6 - Services - known  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:27:27|

242|28426|1|1|124||12||Management of contract (B5) |H3|0.0|||||20/07/2023 02:15:13|

243|28427|1|1|124| F|12.73||Clause 5.1 - Management of the works  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:15:24|

244|28428|1|1|124| G|12.76||Clause 5.2 - Progress meetings  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

245|28429|1|1|124| H|12.79||Clause 5.3 - Technical meetings  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

246|28430|1|1|125||11||Samples, shop drawings and manufacturer's instructions (B6) |H3|0.0|||||20/07/2023 02:15:13|

247|28431|1|1|125| A|11.69||Clause 6.1 - Samples of materials  F:............................. V:............................ T:...........................|Item|1.00|||||20/07/2023 02:15:13|

248|28432|1|1|125| B|11.70||Clause 6.2 - Workmanship samples  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

249|28433|1|1|125| C|11.71||Clause 6.3 - Shop drawings  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

250|28434|1|1|125| D|11.72||Clause 6.4 - Compliance with manufacturer's instructions  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

251|28435|1|1|125||12||Deposits and fees (B7) |H3|0.0|||||20/07/2023 02:15:13|

252|28436|1|1|125| E|12.73||Clause 7.1 - Deposits and fees  F:.......................... V:........................... T:.........................|Item|1.00|||||20/07/2023 02:15:13|

253|28437|1|1|125||12||Temporary services (B8) |H3|0.0|||||20/07/2023 02:15:13|

254|28438|1|1|125| F|12.76||Clause 8.1 - Water  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:30:06|

255|28439|1|1|125| G|12.77||Clause 8.2 - Electricity  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:30:14|

256|28440|1|1|125| H|12.79||Clause 8.3 - Ablution and welfare facilities  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:15:40|

257|28441|1|1|126| A|12.78||Clause 8.4 - Communication facilities  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

258|28442|1|1|126||12||Prime cost amounts (B9) |H3|0.0|||||20/07/2023 02:15:13|

259|28443|1|1|126| B|12.82||Clause 9.1 - Responsibility for prime cost amounts|CONT|0.00|||||20/07/2023 02:15:13|

260|28444|1|1|126||||Where details of materials for which prime cost amounts are to be allowed are readily available, the quantity surveyor may elect to insert the relevant prime cost amounts in measured items, which measured items shall contain sufficient detail for the contractor to price for fixing and installation, waste, etc  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

261|28445|1|1|126||13||Attendance on subcontractors (B10) |H3|0.0|||||20/07/2023 02:15:13|

262|28446|1|1|126| C|12.78||Clause 10.1 - General attendance  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:15:50|

263|28447|1|1|126| D|||Clause 10.2 - Special attendance  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:13|

264|28448|1|1|126||13||General (B11) |H3|0.0|||||20/07/2023 02:15:14|

265|28449|1|1|126| E|13.88||Clause 11.1 - Protection of the works  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:30:57|

266|28450|1|1|126| F|13.89||Clause 11.2 - Protection/isolation of existing works and works occupied in sections F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:14|

267|28451|1|1|126| G|||Clause 11.3 - Security of the works  F:............................. V:............................ T:............................|Item|1.00|||||24/07/2023 10:32:41|

268|28452|1|1|127| A|||Clause 11.4 - Notice before covering work  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:14|

269|28453|1|1|127| B|||Clause 11.5 - Disturbance|CONT|0.0|||||20/07/2023 02:15:14|

270|28454|1|1|127||||Disturbance All work is to be carried out in such a manner as to cause no unacceptable or unreasonable dust, noise, vibrations, nuisance, inconvenience, annoyance and the like to the public, others, other properties and traffic in so far as they exceed the permissible limitations set by government legislation or by the local authority. Any delays, stoppages and the like arising from or in order to comply with the above will not constitute grounds for an adjustment to the construction period or contract value whatsoeverF:........................ V:.........................T:.........................|Item|1.00|||||20/07/2023 02:15:14|

271|28455|1|1|127| C|||Clause 11.6 - Environmental disturbance|CONT|0.0|||||20/07/2023 02:15:14|

272|28456|1|1|127| D|||Controlling all forms of pollution  The contractor shall be responsible for and take all precautions in controlling by whatever means necessary all forms of pollution emanating from the site during the construction period due inter alia to noise, artificial light, wind-blown sand, dust, deposits of mud, etc|CONT|0.0|||||20/07/2023 02:15:14|

273|28457|1|1|127| E|||The contractor is to ensure that all roads which border the site and are used by the contractor during the execution of the works are kept clean and free of any dirt or debris caused by the execution of the works  F:........................ V:.........................T:......................... |Item|1.00|||||20/07/2023 02:15:14|

274|28458|1|1|127| F|||Environmental management plan  The employer has prepared an environmental management plan (EMP). The contractor shall price opposite this item for compliance with all the requirements of such EMP  F:........................ V:.........................T:.........................|Item|1.00|||||18/11/2024 04:13:10|

275|28459|1|1|128| A|||Clause 11.7 - Works cleaning and clearing  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:16:09|

276|28460|1|1|128| B|||Clause 11.8 - Vermin  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:14|

277|28461|1|1|128| C|||Clause 11.9 - Overhand work  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:14|

278|28462|1|1|128| D|||Clause 11.10 - Tenant installations  F:............................. V:............................ T:............................|Item|1.00|||||12/11/2024 10:57:39|

279|28463|1|1|128| E|||Clause 11.11 - Advertising  F:............................. V:............................ T:............................|Item|1.00|||||12/11/2024 10:57:45|

280|28464|1|1|128||17||SECTION  C: SPECIFIC PRELIMINARIES|H2|0.0|||||20/07/2023 02:15:14|

281|33637|1|1|128| F|||Contract Drawings  The drawings issued with the tender documents do not comprise the complete set but serve as a guide only for tendering purposes and for indicating the scope of the work to enable the tenderer to acquaint himself with the nature and extent of the works and the manner in which they are to be executed.  Should any part of the drawings not be clearly understood by the tenderer he shall, before submitting his tender, obtain clarification in writing from the principal agent.|CONT|0.0|||||18/11/2024 04:19:24|

282|33638|1|1|128||||F:............................. V:............................ T:............................|Item|1.00|||||18/11/2024 04:17:44|

283|33639|1|1|129| A|||Trade Names  Wherever a trade name for any product has been described in the document, the tenderer’s attention is drawn to the fact that any other equivalent product may be used subject to the written approval of the architect and principal agent being obtained prior to the closing date for submission of tenders  If prior written approval for an alternative product is not obtained, the product described shall be deemed to have been tendered for|CONT|0.0|||||18/11/2024 04:19:51|

284|33640|1|1|129||||F:............................. V:............................ T:............................|Item|1.00|||||18/11/2024 04:18:37|

285|33643|1|1|129| B|||Authorisation For The Taking of Photographs  The contractor shall obtain prior authorisation from the employer for the making of any sketches or the taking of any photographs of any site, installation, building or civil works belonging to the employer and shall ensure that all personnel, subcontractors and other persons entering the site shall comply with this requirement as well.|CONT|0.0|||||18/11/2024 04:22:46|

286|33644|1|1|129||||F:............................. V:............................ T:............................|Item|1.00|||||18/11/2024 04:21:05|

287|28465|1|1|129| C|||Warranties for materials and workmanship  Where warranties for materials and/or workmanship are called for, the contractor shall obtain a written warranty, addressed to the employer, from the entity supplying the materials and/or executing the work and shall deliver same to the principal agent on final completion of the contract|CONT|0.0|||||20/07/2023 02:15:14|

288|28466|1|1|129||||The warranty shall state that workmanship, materials and installation are warranted for a specific period from the date of practical completion and that any defects that may arise during the specified period shall be made good at the expense of the entity supplying the materials and/or doing the work, upon written notice to do so|CONT|0.0|||||20/07/2023 02:15:14|

289|28467|1|1|130||||The warranty will not be enforced if the work is damaged by defects in the execution of the works, in which case the responsibility for replacement shall rest entirely with the contractor  F:............................. V:............................ T:............................|Item|1.00|||||20/07/2023 02:15:14|

290|28468|1|1|130| A|||Overtime/Night time work  Should overtime be required to be worked for any reason whatsoever, the cost of such overtime is to be borne by the contractor unless the principal agent has specifically authorised, prior to execution thereof, that costs for such overtime are to be borne by the employer  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:33:18|

291|28469|1|1|130| B|||Cooperation of the contractor for cost management  It is specifically agreed that the contractor accepts the obligation of assisting the principal agent in implementing proper cost management. The contractor will be advised by the principal agent of all cost management procedures which will be implemented to ensure that the contract value does not exceed the budget  F:........................ V:.........................T:.........................|Item|1.00|||||20/07/2023 02:15:14|

292|28470|1|1|130| C|||Overloading  The contractor shall take all necessary steps to ensure that no damage occurs due to overloading of any portion of the works or temporary works eg scaffolding, etc. The contractor shall submit details of his proposed loading, storage, plant erection, etc to the principal agent for approval prior to proceeding with such loading, storing or erecting and shall comply with and pay for the principal agent's requirements in connection with the provision of temporary support work, etc. Any damage caused to the works by overloading shall be made good by the contractor at his sole expense  F:........................ V:.........................T:.........................|Item|1.00|||||20/07/2023 02:15:14|

293|28472|1|1|131| A|||Health and safety|CONT|0.0|||||20/07/2023 02:15:14|

294|28473|1|1|131||||Without limiting the generality of the provisions of clause 2.0, the contractor's attention is drawn to the provisions of the Construction Regulations issued in terms of the Occupational Health and Safety Act, 1993 as amended. It is specifically stated that the employer shall prepare a documented health and safety specification for the works and that the employer shall ensure that the contractor has made provision for the cost of health and safety measures during the execution of the works. The  contractor shall price opposite this item for compliance with the act and the regulations and the reasonable provisions of the aforementioned health and safety specification [2.1]||0.0|||||20/07/2023 02:15:14|

295|28474|1|1|131||||The contractor shall:  1.   Comply with the health and safety specification for the works  2.   Prepare and agree with the health and safety consultant the health and  safety plan for the works  3.   Cooperate with the health and safety consultant      in all respects  4.   Manage the compliance of all subcontractors with the regulations and with the health and safety plan and specification  5.   Conform to the conditions contained in the employer's health and safety specification||0.0|||||15/07/2024 04:33:49|

296|28475|1|1|131||||F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:16:21|

297|28476|1|1|132| A|||Confidentiality  The contractor undertakes to maintain in confidence any and all information regarding this project and shall obtain appropriate similar undertakings from all subcontractors and suppliers. Such information shall not be used in any way except in connection with the execution of the works  No information regarding this project shall be published or disclosed without the prior written consent of the employer  F:........................ V:.........................T:.........................|Item|1.00|||||20/07/2023 02:15:15|

298|28478|1|1|132| B|||Propping of floors below  The contractor is advised that propping of floors below may be required if he wishes to use any areas of completed suspended reinforced concrete slabs for vehicle access, storage of materials and goods and location of plant, scaffolding, etc. The location of these areas and any necessary propping shall be approved by the principal agent and the cost thereof shall be borne by the contractor  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:16:32|

299|31876|1|1|132| C|||Site instructions issued on site are to be recorded in triplicate in a site instruction book which is to be maintained on site by the contractor and sent with the monthly claim to the principal agent/quantity surveyor  F:............................. V:............................ T:............................|Item|1.00|||||15/07/2024 04:34:17|

300|33632|1|1|132| D|||V&A Waterfront Rules/Code of Conduct  The Contractor is to comply with the V&A Waterfronts rules and code of conduct during construction as set out by the V&A waterfront.  F:............................. V:............................ T:............................|Item|1.00|||||18/11/2024 04:12:57|

301|33633|1|1|133| A|||Broad based black economic empowerment (BBBEE)  Tenders submitted will be evaluated taking into account their empowerment rating  The employer will be monitoring the broad based black economic empowerment (BBBEE) status of the contractor throughout the execution of the works|CONT|0.0|||||15/11/2024 02:56:04|

302|33634|1|1|133||||The contractor is to submit to the principal agent on an annual basis a schedule of spend, split into vendors engaged as subcontractors and suppliers indicating their BBBEE rating including proof of the said rating  F:........................ V:.........................T:.........................|Item|1.00|||||15/11/2024 02:56:04|

303|33635|1|1|133| B|||Advertising rights  The employer may elect to contract with advertising agencies for the erection of advertising hoardings, banners, wraps or the like for the duration of the contract. The contractor shall not prevent such an arrangement and will assist in the facilitation of same. The position and type of advertising structure to be agreed with the principal agent so as not to hinder the contractor in meeting his obligations under this agreement  F:........................ V:.........................T:.........................|Item|1.00|||||15/11/2024 02:56:19|

304|33636|1|1|133| C|||Media releases  All rights of publication of articles in the media, together with any advertising relating thereto or in any way connected with this project, shall vest with the employer  The contractor together with his subcontractors shall not, without the prior written consent of the employer, cause any statement or advertisement connected with this project to be printed, screened or aired by the media  F:........................ V:.........................T:.........................|Item|1.00|||||15/11/2024 02:56:31|

305|28480|1|1|134||18||SUMMARY OF CATEGORIES|H3|0.0|||||20/07/2023 02:15:15|

306|28484|1|1|134||18||Category : Fixed   R.........................  Category : Value   R.........................  Category : Time    R.........................||0.0|||||15/07/2024 04:17:17|

307|0|1|1|||||||0.0|||||11/06/2025 12:00:00|

308|16692|2|1|137||22||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

309|16693|2|1|137||22||BILL NO 1 |H1|0.0|||||20/07/2023 02:08:24|

310|16694|2|1|137||22||ALTERATIONS |H1|0.0|||||20/07/2023 02:08:24|

311|16695|2|1|137||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:25:33|

312|16696|2|1|137||22||GENERAL|H2|0.0|||||20/07/2023 02:08:24|

313|16697|2|1|137| A|22.A||Tenderers are advised to visit the site and to satisfy themselves as to the nature and extent of the work to be done, and allow for all work not specially mentioned but obviously intended and necessary for the proper completion of the works, as no claim for extra work in connection herewith will be entertained.|Item|1.00|||||20/07/2023 02:08:24|

314|16698|2|1|137| B|22.B||The whole of the old materials from the alterations except as hereinafter stated, or where described to be set aside for re-use, are to become the property of the Client. Old materials specified to be set aside for re-use are to be carefully removed, cleaned, stored, protected from injury and made good as required.|Item|1.00|||||20/07/2023 02:08:24|

315|16699|2|1|137| C|22.C||The Contractor is advised to take all dimensions affecting the existing building on the site as he will be held solely responsible for all new work being of the correct size.|Item|1.00|||||20/07/2023 02:08:24|

316|16700|2|1|137| D|22.D||In demolishing existing work the utmost care is to be observed to avoid any structural or other damage to the remaining portions of the building and external works (pavings, etc). The Contractor must also protect all work not removed such as walls, floors, ceilings, doors, windows or other joinery fittings, etc, from damage during the progress of the work and provide all necessary materials for doing so. The Contractor will be held solely responsible for any structural or other damage to persons or property and for the safety of the structure.|Item|1.00|||||20/07/2023 02:08:24|

317|16701|2|1|138| A|23.A||Allow for making good in all trades to existing work where damaged or disturbed through alterations with all necessary new materials to match and leave complete and perfect in every respect.|Item|1.00|||||20/07/2023 02:08:24|

318|16702|2|1|138| B|23.B||Allow for watering areas of the works with a jet spray sufficiently or dust cover sheets to prevent any nuisance from dust during alterations.|Item|1.00|||||08/08/2023 01:03:52|

319|16703|2|1|138| C|23.C||Give all notices to the Municipality and/or other Authorities and pay all charges legally payable and include for the removal or alteration or disconnection of electrical wires or cables, telephone wires and poles which may be met with, after consultation with the Architect who will indicate which services can be disconnected.|Item|1.00|||||20/07/2023 02:08:24|

320|16704|2|1|138||23||SUPPORTING EXISTING STRUCTURE|H3|0.0|||||20/07/2023 02:08:24|

321|16705|2|1|138| D|23.D||Allow for strutting as necessary, any portion of the work including existing walls, etc, where openings are created in existing walls;  all to ensure the stability of the surrounding structure and building in general, with suitable and substantial timber and other materials for doing so to the approval of the Engineer and remove on completion|Item|1.00|||||23/07/2024 06:51:42|

322|16706|2|1|138||23||TEMPORARY BARRIERS, SCREENS, ETC|H3|0.0|||||20/07/2023 02:08:24|

323|26604|2|1|138||23||Temporary barriers, screens, etc, including removal|H2|0.0|||||20/07/2023 02:08:24|

324|26605|2|1|138| E|||Drywall dust screens/barriers 2 200mm high constructed of galvanised steel channel section rails and studs and covered on both sides with 12,7mm gypsum plasterboard and finished with two coats interior quality PVA emulsion paint, including corners, ends, etc|m|31|||||14/11/2024 09:30:25|

325|26606|2|1|138| F|23.E||Ditto, but 2 400mm high|m|38|||||14/11/2024 12:08:46|

326|33626|2|1|138| G|23.E||Ditto, but 3 050mm high|m|5|||||19/11/2024 04:43:42|

327|26609|2|1|138| H|17.B||Extra over for hollow core single door 813 x 2 032mm high, including steel frame, two-lever mortice lock, primer and two coats paint|No|4|||||20/07/2023 02:08:24|

328|26611|2|1|138| J|17.B||Extra over for hollow core double door 1 500 x 2 032mm high, including steel frame, two-lever mortice lock, primer and two coats paint|No|4|||||20/07/2023 02:08:24|

329|16712|2|1|139||23||REMOVAL OF EXISTING WORK|H3|0.0|||||20/07/2023 02:08:24|

330|16716|2|1|139||23||Breaking down, removing and carting away brickwork, etc.|H2|0.0|||||23/07/2024 06:52:03|

331|16718|2|1|139| A|||Demolish 220mm walls |m2|12|||||20/07/2023 02:08:24|

332|16722|2|1|139||24||Hacking off, removing and carting away floor/wall finishes including all adhesives and preparing concrete or brick surfaces for new finishes|H2|0.0|||||20/07/2023 02:08:24|

333|32859|2|1|139| B|24.E||Remove 600 x 600mm large format slate floor tiles and scabble existing floor for new floor finish|m2|90|||||14/11/2024 12:06:28|

334|33301|2|1|139| C|24.F||Chip off loose paint from existing walls and prepare surface for new paint|m2|395|||||12/11/2024 01:53:01|

335|33549|2|1|139| D|24.F||Chip off loose paint from existing columns and prepare surface for new paint|m2|32|||||14/11/2024 09:27:12|

336|29508|2|1|139| E|24.F||Remove existing wall tiles and adhesives and prepare existing surface to receive new wall finish|m2|68|||||14/11/2024 01:07:50|

337|33586|2|1|139| F|24.F||Remove existing wall paper and adhesives from existing walls and prepare existing surfaces to receive new wall paper|m2|33|||||15/11/2024 09:36:31|

338|19200|2|1|139| G|24.F||Remove existing wall tiles and adhesives from walls to be demolished (demolition measured elsewhere)|m2|24|||||07/08/2023 05:37:13|

339|20729|2|1|139| H|||100mm High slate tile skirting from walls|m|245|||||19/11/2024 04:43:57|

340|33302|2|1|139| J|34.8||Remove timber skirting from walls|m|5|||||19/11/2024 04:43:55|

341|16727|2|1|139| K|||Take down stainless steel corner protectors 2 200mm high|No|3|||||14/11/2024 12:15:40|

342|32874|2|1|139| L|||Ditto, but 2 400mm high|No|14|||||15/11/2024 11:08:34|

343|33295|2|1|139||||Taking up and removing wood block floor coverings, vinyl floor coverings, carpets, etc and preparing screeds for new floor finish|H2|0.0|||||14/11/2024 12:13:14|

344|33296|2|1|139| M|||Remove carpet tile floor coverings including adhesives and scabble existing floor for new floor finish|m2|259|||||14/11/2024 12:13:46|

345|16728|2|1|140||24||Taking down and removing roofs, ceilings, bulkheads, dry wall partitioning, etc including carting away and dumping on a site located by the Contractor|H2|0.0|||||23/07/2024 06:54:03|

346|16729|2|1|140| A|24.J||Timber slatted suspended ceiling with MDF backing, complete including timber/steel support grid, cornices, etc.|m2|88|||||18/11/2024 04:50:01|

347|20393|2|1|140| B|24.J||Plasterboard suspended ceiling, complete including timber/steel support grid, cornices, etc.|m2|165|||||12/11/2024 01:28:09|

348|16731|2|1|140| C|||Plasterboard bulkhead 200mm high including steel bulkhead supports|m|7|||||14/11/2024 10:45:19|

349|33621|2|1|140| D|||Ditto, but 650mm high|m|25|||||15/11/2024 02:11:29|

350|32856|2|1|140| E|24.J||Drywall partitions approximately 2 400mm high including all frames, grids, supports, fittings, etc|m|49|||||14/11/2024 12:04:02|

351|33627|2|1|140| F|24.J||Drywall partitions approximately 3 050mm high including all frames, grids, supports, fittings, etc|m|4|||||15/11/2024 02:31:35|

352|33591|2|1|140| G|24.J||Drywall partitions approximately 3 950mm high including all frames, grids, supports, fittings, etc|m|3|||||15/11/2024 10:04:53|

353|33596|2|1|140| H|24.J||Toilet cubicle partitioning made of 20mm thick vitreous enamelled steel sheet faced particle board bonded panels, approximately 2 100mm high including all frames, stiles, grids, supports, fittings, etc|m|14|||||18/11/2024 04:50:44|

354|33350|2|1|140| J|24.J||Aluminium framed enclosure partitions approximately 2 400mm high overall, with two fixed panes with glazing to the top pane approximately 1 600mm high and bottom pane fitted with solid timber boarding approximately 800mm high including all frames, grids, supports, fittings, etc|m|8|||||14/11/2024 12:03:48|

355|16732|2|1|140||||Taking out and removing doors, windows, etc including frames, thresholds, ironmongery, sills, etc from brickwork|H2|0.0|||||14/11/2024 01:01:18|

356|16733|2|1|140| K|||Timber single door and steel frame 813 x 2 032mm high overall|No|2|||||20/07/2023 02:08:24|

357|20413|2|1|140| L|||Strong room door and frame, approximate size 1 100mm x  2 100mm high|No|1|||||14/11/2024 10:05:25|

358|33585|2|1|141| A|||Aluminium framed trellis sliding door, overall size 3 000mm x 2 200mm high including sliding track and frame|No|1|||||15/11/2024 09:34:21|

359|33370|2|1|141| B|||Glazed timber double shopfront door and frame, size 1 600 x 2 200mm high overall including glazing|No|1|||||14/11/2024 01:01:08|

360|33584|2|1|141| C|||Glazed timber double shopfront door and frame, size 1 700 x 2 200mm high overall including glazing|No|1|||||15/11/2024 09:28:02|

361|33567|2|1|141| D|||Aluminium double sliding door size 1 850 x 2 200mm high overall including glazing|No|1|||||14/11/2024 10:56:09|

362|26780|2|1|141| E|||Aluminium framed single shopfront door, overall size 1 000 x 2 400mm high with two fixed panes with glazing to the top pane approximately 1 000 x 1 600mm high and bottom pane fitted with solid timber boarding approximately 1 000 x 800mm high including all frames, ironmongery, etc.|No|1|||||14/11/2024 12:12:13|

363|33550|2|1|141| F|||Glazed aluminium shopfronts including glazing and frame exceeding 7.50m² and not exceeding 10m²|No|2|||||14/11/2024 09:34:47|

364|32867|2|1|141| G|||Glazed aluminium shopfronts including doors, glazing and frame exceeding 7.50m² and not exceeding 10m²|No|1|||||14/11/2024 09:34:38|

365|33615|2|1|141| H|||Glazed aluminium shopfronts including doors, glazing and frame exceeding 10m² and not exceeding 12.5m²|No|1|||||15/11/2024 01:51:27|

366|33581|2|1|141| J|||Glazed aluminium shopfronts including stacking doors, glazing and frame exceeding 10m² and not exceeding 12.50m²|No|1|||||15/11/2024 09:23:27|

367|33354|2|1|141||||Taking out and removing doors, windows, etc including frames, thresholds, ironmongery, sills, etc from drywall partitions|H2|0.0|||||15/11/2024 10:43:37|

368|33366|2|1|141| K|||Timber single door and aluminium frame 813 x 2 032mm high overall|No|4|||||14/11/2024 12:56:18|

369|33582|2|1|141| L|||Timber single door and aluminium frame 900 x 2 200mm high overall|No|2|||||15/11/2024 09:24:17|

370|33367|2|1|141| M|||Timber single door and aluminium frame 900 x 2 400mm high overall|No|5|||||14/11/2024 12:56:36|

371|33583|2|1|142| A|||Timber double door and solid hardwood timber frame 1 700 x 2 400mm high overall|No|3|||||15/11/2024 09:26:22|

372|33355|2|1|142| B|||Aluminium window with two sliding glass panes overall size 1 800 x 1 200mm high including glazing|No|1|||||14/11/2024 12:20:35|

373|33579|2|1|142| C|||Aluminium window with two sliding glass panes overall size 1 200 x 1 500mm high including glazing|No|1|||||15/11/2024 09:22:10|

374|33580|2|1|142| D|||Aluminium window with one fixed glass pane overall size 1 500 x 1 500mm high including glazing|No|1|||||15/11/2024 09:22:04|

375|33578|2|1|142| E|||Glazed aluminium shopfronts including glazing and frame not exceeding 5m²|No|3|||||15/11/2024 09:14:52|

376|33356|2|1|142| F|||Glazed aluminium shopfronts including glazing and frame exceeding 7.50m² and not exceeding 10m²|No|3|||||14/11/2024 12:23:40|

377|33597|2|1|142||||Taking out and removing doors, windows, etc including frames, thresholds, ironmongery, sills, etc from toilet cubicle partitions|H2|0.0|||||15/11/2024 10:47:19|

378|33598|2|1|142| G|||Toilet cubicle single door and frame 762 x 2 100mm high overall|No|6|||||15/11/2024 10:45:38|

379|33599|2|1|142| H|||Toilet cubicle single door and frame 813 x 2 100mm high overall|No|1|||||15/11/2024 10:45:53|

380|33352|2|1|142||||Taking out and removing doors, etc, setting aside/stockpiling on site for re-use and later refixing in similar or new position|H2|0.0|||||14/11/2024 01:47:55|

381|33568|2|1|142| J|||Timber single door from timber frame 813 x 2 032mm high overall|No|1|||||14/11/2024 10:56:58|

382|33353|2|1|142| K|||Timber single door from timber frame 900 x 2 400mm high overall|No|6|||||14/11/2024 12:18:10|

383|33284|2|1|142||||Taking out and removing ironmongery|H2|0.0|||||12/11/2024 01:40:46|

384|33285|2|1|142| L|||Mortice lockset from timber door|No|4|||||14/11/2024 12:28:23|

385|33359|2|1|142| M|||WC indicator bolt lockset from timber door|No|3|||||14/11/2024 12:28:51|

386|33358|2|1|142| N|||Door pull handle from timber door|No|8|||||14/11/2024 12:28:18|

387|33289|2|1|142| P|||Hat and coat hook from timber door|No|5|||||14/11/2024 12:30:20|

388|33361|2|1|143| A|||Emblem/nameplate size 150 x 150mm high approximately for toilets with male, female or disabled sign from timber door|No|5|||||14/11/2024 12:34:28|

389|33363|2|1|143| B|||Louvre unit, 750mm x 150mm high approximately from timber door|No|6|||||14/11/2024 06:49:16|

390|33362|2|1|143| C|||Pushplate, 800mm x 150mm high approximately from timber door|No|4|||||14/11/2024 12:38:05|

391|33360|2|1|143| D|||Kickplate, 900mm x 300mm high approximately from timber door|No|6|||||14/11/2024 12:31:45|

392|33286|2|1|143| E|||Door closer from timber door and frame|No|5|||||14/11/2024 12:28:27|

393|33287|2|1|143| F|||Grab rail not exceeding 1 000mm long from wall|No|3|||||14/11/2024 12:26:51|

394|33288|2|1|143| G|||Toilet paper roll holder from wall|No|10|||||14/11/2024 01:02:49|

395|33365|2|1|143| H|||Paper towel dispenser from wall|No|5|||||14/11/2024 12:48:56|

396|33600|2|1|143| J|||Automatic hand dryer from wall|No|3|||||15/11/2024 10:50:28|

397|33371|2|1|143| K|||Paper towel disposal bin from wall|No|5|||||14/11/2024 01:03:12|

398|33368|2|1|143| L|||Soap dispenser from wall|No|5|||||14/11/2024 12:58:47|

399|33604|2|1|143| M|||Urinial divider screen from wall|No|1|||||15/11/2024 11:07:48|

400|32857|2|1|143||||Taking out and removing sundry metal work, fittings, etc|H2|0.0|||||22/07/2024 05:21:04|

401|32860|2|1|143| N|||48 Diameter x 5.34mm Thick steel bumper rails welded to base plates which are bolted down by chemical anchor bolts|m|6|||||19/11/2024 04:44:12|

402|33283|2|1|143| P|||Strong room ventilation grille and frame, approximate size 300mm x 300mm high|No|2|||||14/11/2024 10:07:00|

403|16746|2|1|143||||Taking out and removing piping, sanitary fittings, etc including disconnecting piping from fittings, and making good floor and wall finishes|H2|0.0|||||20/07/2023 02:08:24|

404|33570|2|1|143| Q|||Stainless steel single bowl sink|No|1|||||14/11/2024 11:00:28|

405|26343|2|1|143| R|||Stainless steel double bowl sink|No|1|||||20/07/2023 02:08:24|

406|26854|2|1|144| A|||Vitreous china wall hung urinals with flush valves and flush pipes including wastes, traps, taps, etc.|No|2|||||14/11/2024 01:10:51|

407|32870|2|1|144| B|||Vitreous china wall hung wash hand basin including wastes, traps, taps, etc.|No|8|||||14/11/2024 01:11:01|

408|26853|2|1|144| C|||Vitreous china water closet pan with concealed cistern and flush pipe|No|10|||||20/07/2023 02:08:24|

409|26857|2|1|144||||Taking out/off and removing glass and mirrors|H2|0.0|||||20/07/2023 02:08:24|

410|26855|2|1|144| D|||Mirror 600 x 1 000mm high from wall including making good wall where mirror was removed|No|2|||||14/11/2024 12:48:18|

411|33569|2|1|144| E|||Mirror 2 000 x 1 300mm high from wall including making good wall where mirror was removed|No|1|||||14/11/2024 10:59:03|

412|33601|2|1|144| F|||Mirror 600 x 1 400mm high from wall including making good wall where mirror was removed|No|1|||||15/11/2024 12:00:57|

413|33602|2|1|144| G|||Mirror 2 080 x 1 400mm high from wall including making good wall where mirror was removed|No|1|||||15/11/2024 12:01:02|

414|33603|2|1|144| H|||Mirror 2 630 x 1 400mm high from wall including making good wall where mirror was removed|No|1|||||15/11/2024 12:01:07|

415|16757|2|1|144||25||BUILDING UP OPENINGS|H3|0.0|||||20/07/2023 02:08:24|

416|16758|2|1|144||25||Brickwork in class II mortar in building up openings|H2|0.0|||||20/07/2023 02:08:24|

417|26798|2|1|144| J|25.H||280mm Brick cavitywall|m2|3|||||20/07/2023 02:08:24|

418|20736|2|1|144||25||Sundries|H2|0.0|||||20/07/2023 02:08:24|

419|29512|2|1|144| K|25.H||Cutting toothings and bonding new 280mm cavity brickwork to existing brickwork|m2|1|||||07/08/2023 07:45:32|

420|16760|2|1|144||25||MAKING GOOD OF FINISHES, ETC|H3|0.0|||||20/07/2023 02:08:24|

421|16761|2|1|144||25||Making good internal cement plaster|H2|0.0|||||20/07/2023 02:08:24|

422|19218|2|1|144| L|||Where 220mm brickwalls removed|m|6|||||20/07/2023 02:08:24|

423|33557|2|1|144| M|||Where 270mm brick cavitywalls removed|m|10|||||14/11/2024 10:00:50|

424|16764|2|1|145||25||Making good concrete slabs and screeds|H2|0.0|||||08/08/2023 01:07:20|

425|19220|2|1|145| A|25.M||Floors where 220mm brickwalls removed|m2|2|||||20/07/2023 02:08:24|

426|33558|2|1|145| B|25.M||Floors where 270mm brick cavitywalls removed|m2|2|||||14/11/2024 10:01:09|

427|33560|2|1|145||25||Making good soffits of concrete beams and skim plaster|H2|0.0|||||14/11/2024 10:09:20|

428|33561|2|1|145| C|25.M||Where 270mm brick cavitywalls removed|m2|2|||||14/11/2024 10:09:27|

429|19221|2|1|145||||OPENINGS THROUGH EXISTING WALLS ETC|H3|0.0|||||20/07/2023 02:08:24|

430|19222|2|1|145||||Breaking out for and forming openings through brick/block walls for new doors and frames, shopfronts,etc. including brick lintels, making good cement plaster on both sides and into reveals with steel trowelled finish (new doors and frames and making good paintwork measured elsewhere)|H2|0.0|||||14/11/2024 11:39:56|

431|33349|2|1|145| D|||Opening for aluminium fixed shopfront with aluminium frame, size 1 460 x 2 400mm high overall through 220mm brickwall|No|1|||||14/11/2024 07:36:19|

432|33556|2|1|145| E|||Opening, size 4 142 x 2 400mm high overall through 270mm brick cavitywall|No|2|||||14/11/2024 09:49:40|

433|0|2|1|||||||0.0|||||11/06/2025 12:00:00|

434|15133|2|2|147||||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

435|15134|2|2|147||34||BILL NO 2|H1|0.0|||||15/11/2024 02:48:31|

436|15135|2|2|147||34||WATERPROOFING |H1|0.0|||||20/07/2023 02:08:24|

437|33646|2|2|147||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:25:46|

438|17740|2|2|147||||SUPPLEMENTARY PREAMBLES|H3|0.0|||||20/07/2023 02:08:24|

439|17741|2|2|147||||Waterproofing|H2|0.0|||||20/07/2023 02:08:24|

440|17742|2|2|147||||Waterproofing of roofs, basements, etc shall be laid under a ten year guarantee. Waterproofing to roofs shall be laid to even falls to outlets etc with necessary ridges, hips and valleys. Descriptions of sheet or membrane waterproofing shall be deemed to include additional labour to turn-ups and turn-downs||0.0|||||20/07/2023 02:08:24|

441|15139|2|2|147||45||SEALING STRIPS, JOINT SEALANTS, ETC |H3|0.0|||||20/07/2023 02:08:24|

442|15140|2|2|147||45||Approved polyurethane joint sealant dressed into joint, including protecting adjoining surfaces with masking tape|H2|0.0|||||20/07/2023 02:08:24|

443|29239|2|2|147| A|55.A||5 x 5mm Sealer in joint between floor and wall tiles or skirting tiles|m|214|||||31/07/2023 01:09:13|

444|33305|2|2|147||||Movement joint of Jointex or equivalent and approved closed cell expanded polyethylene pre-formed expansion joint filler including "Polycord" and necessary blocking piece for tearing out later including required formwork|H2|0.0|||||12/11/2024 02:37:12|

445|33306|2|2|147| B|||10mm Thick Jointex or equivalent and approved not exceeding 300mm wide vertically between brickwork and concrete columns/walls|m|4|||||19/11/2024 04:43:29|

446|22543|2|2|148||||Sikaflex Pro 2HP or equivalent and approved polyurathane joint sealant dressed into joint, including cleaning an priming both sides  with Sikaflex primer - 3 strip or equivalent and approved product all in accordance with manufacturer's instructions|H2|0.0|||||18/11/2024 04:55:09|

447|33307|2|2|148| A|||10mm Wide x 10mm deep dressed in movement joints between concrete column and brickwork|m|8|||||19/11/2024 04:43:32|

448|0|2|2|||||||0.0|||||11/06/2025 12:00:00|

449|15106|2|3|150||||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

450|15107|2|3|150||35||BILL NO 3|H1|0.0|||||15/11/2024 02:48:35|

451|15108|2|3|150||35||CARPENTRY AND JOINERY |H1|0.0|||||20/07/2023 02:08:24|

452|33647|2|3|150||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:25:57|

453|19326|2|3|150||||SUPPLEMENTARY PREAMBLES|H3|0.0|||||20/07/2023 02:08:24|

454|19327|2|3|150||||Fixing|H2|0.0|||||20/07/2023 02:08:24|

455|19328|2|3|150||||Items described as "nailed" shall be deemed to be fixed with hardened steel nails or pins, or to be shot-pinned, to brickwork/blockwork or concrete||0.0|||||20/07/2023 02:08:24|

456|19329|2|3|150||||Items described as "plugged" shall be deemed to include screwing to fibre, plastic or metal plugs at not exceeding 500mm centres, and where described as "bolted", the bolts have been given elsewhere, unless otherwise described||0.0|||||20/07/2023 02:08:24|

457|19330|2|3|150||||Joinery|H2|0.0|||||20/07/2023 02:08:24|

458|19331|2|3|150||||Descriptions of frames shall be deemed to include frames, transomes, rails, etc||0.0|||||20/07/2023 02:08:24|

459|19332|2|3|150||||Descriptions of hardwood joinery shall be deemed to include sinking and pelleting heads and nuts of bolts||0.0|||||20/07/2023 02:08:24|

460|19333|2|3|150||44||Fire doors|H2|0.0|||||20/07/2023 02:08:24|

461|19334|2|3|150||44||Fire doors are to be in accordance with SANS 1253||0.0|||||20/07/2023 02:08:24|

462|15113|2|3|151||127||DOORS, ETC |H3|0.0|||||20/07/2023 02:08:24|

463|33394|2|3|151||78||Reinstatement of existing timber doors from stockpile on site|H2|0.0|||||14/11/2024 01:48:19|

464|33395|2|3|151||127||Solid core flush doors with 3mm tempered hardboard to both faces with two concealed hardwood edges and 100% solid timber core from stockpile on site, hung to existing timber frames|H2|0.0|||||14/11/2024 01:51:26|

465|33571|2|3|151| A|||40mm Door size 813 x 2 032mm high|No|1|||||19/11/2024 04:44:22|

466|33396|2|3|151| B|||40mm Door size 900 x 2 400mm high with one 750 x 150mm framed opening for air grille (louvre unit measured elsewhere)|No|6|||||19/11/2024 04:44:25|

467|33397|2|3|151||78||Supply and installation of new timber doors|H2|0.0|||||14/11/2024 01:50:33|

468|33562|2|3|151||127||Solid core flush doors with 3mm tempered hardboard to both faces with two concealed hardwood edges and 100% solid timber core, hung to timber frames|H2|0.0|||||18/11/2024 04:56:17|

469|33563|2|3|151| C|||40mm Door size 915 x 2 134mm high|No|1|||||19/11/2024 04:44:29|

470|33379|2|3|151||70||FRAMED FRAMES, ETC. |H3|0.0|||||14/11/2024 02:59:11|

471|33380|2|3|151||70||"Swartland" or equivalent and approved wrought meranti frames|H2|0.0|||||18/11/2024 04:56:34|

472|33381|2|3|151| D|||50 x 75mm Rebated frames|m|28|||||14/11/2024 01:16:05|

473|33618|2|3|151||||FLOORS|H3|0.0|||||15/11/2024 01:56:36|

474|33616|2|3|151||36||Making good existing timber floors/skirtings and sub-structure by sanding and resealing existing timber including taking out where necessary, sanding, sealing and reinstatement of timber floor where necessary to|H2|0.0|||||15/11/2024 02:00:38|

475|33617|2|3|151| E|36.35||Timber floors|m2|123|||||15/11/2024 01:58:42|

476|33620|2|3|151| F|36.35||Timber skirtings|m|60|||||15/11/2024 02:00:57|

477|33382|2|3|152||71||CUPBOARDS TO KITCHENS, BEDROOMS, ETC|H3|0.0|||||14/11/2024 02:59:31|

478|33383|2|3|152||71||SUPPLEMENTARY PREAMBLES|H2|0.0|||||14/11/2024 02:59:40|

479|33384|2|3|152||72||General|H4|0.0|||||14/11/2024 01:16:27|

480|33385|2|3|152||72||The following cupboard fittings are given as complete units i.e. the components of the units have not been given separately. Descriptions of such units shall, therefore, be deemed to include all components, assembling, housing, notching, glueing, blocking, planting-on and screwing with countersunk screws, edge strips, thermosetting plastic laminate, glass, ironmongery, metalwork, paint or varnish finishes, etc Prices are to include for all necessary filler pieces against walls etc||0.0|||||14/11/2024 01:16:27|

481|33386|2|3|152||72||Worktops, Floor Cupboards, Wall Cupboards, etc|H2|0.0|||||18/11/2024 04:57:14|

482|33387|2|3|152||77||Kitchenette cupboards, desks, etc. complete as per Architect's specifications and drawings, including all necessary ironmongery to be approved by the Architect (Refer to architect drawing no. A501)|H4|0.0|||||14/11/2024 03:02:02|

483|33572|2|3|152| A|||Kitchen floor cupboard unit, 2 000mm long x 730mm wide x 900mm high made up of 16mm melamine faced particle board carcass (colour: white) and 16mm PG Bison or equivalent and approved "Supamatt" boards with matte finish to the fronts of the unit (colour: TBC) with 16mm melamine adjustable shelving inside floor cupboard unit and 2mm impact edging all round, unit to be placed on top of surface bed, including 150mm high powder coated aluminium kick plate (colour: TBC) to the bottom of the cupboard, with opening suitable for one stainless steel double bowl sink unit (sink measured elsewhere) including all necessary framing to the sides, back, bottom and base and including drawers with full extension soft close runners, handless finger pull grooves with push to open mechanism and including cupboard doors with soft close concealed hinges and handless finger pull grooves with push to open, installed complete with all necessary fixing, cleats, strips and studs, etc. all as per Architects specification (Refer to Architect Drawing no. A501)|No|1|||||18/11/2024 04:58:07|

484|33573|2|3|153| A|||Wall mounted floating open shelving system, 2 000mm long x 400mm deep x 800mm high, carcass of 25mm thick PG Bison or equivalent and approved "Supamatt" boards with matte finish (colour: TBC) with 2mm impact edging all round. Unit consists of two shelves and one vertical divider, installed complete with all necessary fixing, cleats, strips and studs, etc. all as per Architects specification (Refer to Architect Drawing no. A501)|No|1|||||18/11/2024 04:59:54|

485|33388|2|3|153| B|||U-shaped kitchen floor cupboard unit, 5 750mm long x 600mm wide x 900mm high made up of 16mm melamine faced particle board carcass (colour: white) and 16mm PG Bison or equivalent and approved "Supamatt" boards with matte finish to the fronts of the unit (colour: TBC) with 16mm melamine adjustable shelving inside floor cupboard unit and 2mm impact edging all round, unit to be placed on top of surface bed, including 150mm high powder coated aluminium kick plate (colour: TBC) to the bottom of the cupboard, with opening suitable for one stainless steel double bowl sink unit (sink measured elsewhere) including all necessary framing to the sides, back, bottom and base and including drawers with full extension soft close runners, handless finger pull grooves with push to open mechanism and including cupboard doors with soft close concealed hinges and handless finger pull grooves with push to open, installed complete with all necessary fixing, cleats, strips and studs, etc. all as per Architects specification (Refer to Architect Drawing no. A501)|No|1|||||18/11/2024 05:00:28|

486|33400|2|3|153| C|||U-shaped wall mounted floating open shelving system, 5 750mm long x 400mm deep x 800mm high, carcass of 25mm thick PG Bison or equivalent and approved "Supamatt" boards with matte finish (colour: TBC) with 2mm impact edging all round. Unit consists of six shelves and three vertical dividers, installed complete with all necessary fixing, cleats, strips and studs, etc. all as per Architects specification (Refer to Architect Drawing no. A501)|No|1|||||18/11/2024 05:00:08|

487|33391|2|3|153| D|75.68||Stationary + printers desk, 6 050mm long x 600mm wide x 750mm high made up of 16mm PG Bison or equivalent and approved "Supamatt" board with matte finish (colour: TBC) including 2mm impact edging all round and including all necessary framing to the sides, back, bottom and base, installed complete with all necessary support legs, brackets, fixing, cleats, strips and studs, etc. all as per Architects specification (Refer to Architect Drawing no. A501)|No|1|||||14/11/2024 03:45:26|

488|33372|2|3|154||||VANITY SLABS, COUNTERS, ETC|H3|0.0|||||14/11/2024 01:15:08|

489|33398|2|3|154||86||20mm thick "Caesarstone Quartz" or equivalent and approved counter tops, (Colour: TBC)|H2|0.0|||||14/11/2024 03:37:45|

490|33574|2|3|154| A|||Polished engineered stone counter top to top of kitchen floor cupboard unit, size 2 000mm long x 730mm wide x 25mm thick, including one cut-out for double bowl sink, size 1 160 x 460mm,  installed complete with all necessary mitred edges, fixing, brackets, cleats, strips and studs, etc. all as per Architects specification (Refer to Architect Drawing no. A501)|No|1|||||14/11/2024 11:09:23|

491|33399|2|3|154| B|||U-shaped polished engineered stone counter top to top of kitchen floor cupboard unit, size 5 750mm long x 600mm wide x 25mm thick, including one cut-out for double bowl sink, size 1 160 x 460mm,  installed complete with all necessary mitred edges, fixing, brackets, cleats, strips and studs, etc. all as per Architects specification (Refer to Architect Drawing no. A501)|No|1|||||14/11/2024 03:41:13|

492|33373|2|3|154||||Purpose made engineered stone wash hand basin trough/vanity formed of 100mm thick engineered stone to Architects approval (colour: TBC) fixed to and including galvanised mild steel angle sub-frame and sub-frame fixed to brickwork, including all necessary support structures, bolts, etc, complete|H2|0.0|||||18/11/2024 05:02:24|

493|33374|2|3|154| C|||Wash hand basin vanity unit, size approximately 2 080 x 500 x 100mm thick at 700mm high above finished floor level, including cut out for drainage slot/channel sized 1 980mm long x 20mm wide, including brackets, screws, strips, etc. Installed complete|No|1|||||15/11/2024 11:52:23|

494|33605|2|3|154| D|||Wash hand basin vanity unit, size approximately 2 630 x 500 x 100mm thick at 700mm high above finished floor level, including cut out for drainage slot/channel sized 2 540mm long x 20mm wide, including brackets, screws, strips, etc. Installed complete|No|1|||||15/11/2024 11:53:25|

495|0|2|3|||||||0.0|||||11/06/2025 12:00:00|

496|15061|2|4|156||||SECTION 2|H1|0.0|||||24/07/2023 12:27:51|

497|15062|2|4|156||38||BILL NO 4|H1|0.0|||||15/11/2024 02:48:39|

498|15063|2|4|156||38||CEILINGS, PARTITIONS & ACCESS FLOORS |H1|0.0|||||20/07/2023 02:08:24|

499|33648|2|4|156||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:26:03|

500|20747|2|4|156||38||SUPPLEMENTARY PREAMBLES  DESCRIPTIONS  Items described as "nailed" shall be deemed to be fixed with hardened nails or pins or shot pinned to brickwork or concrete.  Items described as "plugged" shall be deemed to include screwing to fibre, plastic or metal plugs at not exceeding 600mm centres, and where described as "bolted" the bolts have been given elsewhere.||0.0|||||20/07/2023 02:08:24|

501|20748|2|4|156||41||Fixing|H2|0.0|||||20/07/2023 02:08:24|

502|20749|2|4|156||41||Items described as "nailed" shall be deemed to be fixed with hardened steel nails or pins, or to be shot-pinned, to brickwork or concrete||0.0|||||20/07/2023 02:08:24|

503|20750|2|4|156||41||Items described as "plugged" shall be deemed to include screwing to fibre, plastic or metal plugs at not exceeding 500mm centres, and where described as "bolted", the bolts have been given elsewhere||0.0|||||20/07/2023 02:08:24|

504|20751|2|4|156||41||Ceilings|H2|0.0|||||20/07/2023 02:08:24|

505|20752|2|4|156||41||Unless otherwise described ceilings shall be deemed to be horizontal||0.0|||||20/07/2023 02:08:24|

506|20753|2|4|157||41||Steel components|H2|0.0|||||20/07/2023 02:08:24|

507|20754|2|4|157||41||All steel components for ceilings, partitions, etc are to be galvanised in accordance with SANS 121||0.0|||||20/07/2023 02:08:24|

508|20755|2|4|157||42||Suspended ceilings|H2|0.0|||||20/07/2023 02:08:24|

509|20756|2|4|157||42||Hangers, suspension grids, "lay-in" panels, etc are to be in accordance with the manufacturers' recommendations||0.0|||||20/07/2023 02:08:24|

510|20757|2|4|157||42||Electrical light fittings, diffusers, panels etc are generally "lay-in" units of the same dimensions as the suspension grid described and allowance must be made in the rates accordingly for their support inclusive of any flexibility in setting out that may be required (ceiling panels have not been deducted and pricing is to take cognisance thereof)||0.0|||||20/07/2023 02:08:24|

511|20758|2|4|157||54||All suspended ceilings to be Saint Gobain Gyproc or equivalent and approved galvanized steel suspension ceiling grid system. Ceiling grids to consist of Gyproc or equivalent and approved 25 x 25mm Wall angle fixed to the perimeter wall using fixings at 300mm centres. Gyproc or equivalent and approved 38 x 38mm Main Tees at 1 200mm centres, Suspend main tees using Gyproc or equivalent and approved pre-stretched galvanised Hanger wire 5mm thick or Gyproc or equivalent and approved galvanised rods 5mm thick at 1 200mm centres. The hanger wire shall be put through the main tees hole and would wind 3 times around itself. 2 Steel pop-rivets or one Gyproc or equivalent and approved Wafer Head Tek screw 13mm shall be used to fix the hanger strap to the main tees web. Install Gyproc or equivalent and approved Cross Tees 38 x 25mm (1 200mm long) at 600mm centres to create a 1200 x 600mm ceiling grid. Main tees should be fixed to the wall using angle cleats.||0.0|||||18/11/2024 05:11:25|

512|20765|2|4|158||38||CEILINGS, CORNICES, ETC|H3|0.0|||||20/07/2023 02:08:24|

513|20766|2|4|158||38||SUSPENDED CEILINGS|H2|0.0|||||20/07/2023 02:08:24|

514|20768|2|4|158||38||DESCRIPTIONS  All suspended ceilings to be Saint Gobain Gyproc or equivalent and approved galvanized steel suspension ceiling grid system, fixed to concrete soffits using hanger brackets and 6mm expansion anchors at 1 200mm centres or to steel purlins (on approximately 1,7m centres) and to ceiling tees at 1 200mm centres, Gyproc or equivalent and approved 38 x 38mm galvanised steel main tee sections at 1 200mm centres with cut tee sections in between. The suspended framework strengthened as necessary to create a rigid ceiling platform all in strict accordance to the manufacturer's specification.||0.0|||||14/11/2024 03:59:08|

515|33401|2|4|158||||22mm thick OWAcoustic Ideatec Ideawood (timber colour: lacquered) or equivalent and approved timber slatted ceiling panels with MDF backing board (backing board colour: black), size 2 430 x 140mm, on OWAconstruct S3 white galvanised mild steel exposed demountable T24 or equivalent and approved tee suspension system, including OWAconstruct or equivalent and approved main and cross tees with main tees to be suspended by means of galvanised hangers at centres not exceeding 1 200mm, hangers to be made up of 2.5mm thick galvanised wire and to be bracketed and shot into concrete soffits or fixed purlins as per manufacturer's instructions|H2|0.0|||||14/11/2024 04:19:52|

516|33402|2|4|158| A|||Ceilings suspended not exceeding 1m below soffit of concrete slabs|m2|88|||||14/11/2024 04:10:46|

517|28482|2|4|158||||12.5mm "Saint-Gobain Gyproc" or equivalent and approved tapered edge plasterboard board ceiling flush jointed (Gyproc or equivalent and approved fibreglass mesh taped joints skimmed and painted) on Gyproc or equivalent and approved galvanized steel suspension ceiling grid system fixed at 300mm centers in the field of the boards with Gyproc or equivalent and approved jointing compound in joints and minimum 5mm thick smooth Gypsum Cretestone or equivalent and approved skim plaster finish to a smooth polish surface|H2|0.0|||||14/11/2024 04:07:07|

518|32311|2|4|158| B|||Ceilings suspended not exceeding 1m below soffit of concrete slabs|m2|164|||||14/11/2024 04:07:25|

519|26316|2|4|159||||Sundries|H2|0.0|||||20/07/2023 02:08:24|

520|24349|2|4|159| A|||Standard Saint Gobain or equivalent and approved trap door/access panel size 600mm x 600mm (Provisional)|No|9|||||18/11/2024 05:13:35|

521|20779|2|4|159||56||Cornices to ceilings|H2|0.0|||||20/07/2023 02:08:24|

522|22739|2|4|159| B|||Gyproc or equivalent and approved SM25 aluminium profile recessed wall angle pre painted shadowline cornice plugged|m|276|||||14/11/2024 04:22:00|

523|23330|2|4|159| C|||12.5mm Plaster trim|m|40|||||14/11/2024 04:49:44|

524|22732|2|4|159||131||Openings (Provisional)|H2|0.0|||||20/07/2023 02:08:24|

525|22733|2|4|159| D|||Extra over skimmed plasterboard ceilings for 275mm diameter openings for light fittings including extra hangers and support tee's etc.|No|16|||||15/11/2024 02:07:48|

526|22734|2|4|159| E|||Extra over skimmed plasterboard ceilings for 150mm diameter openings for ventilation grilles including extra hangers and support tee's etc.|No|1|||||14/11/2024 04:30:05|

527|33564|2|4|159| F|||Extra over skimmed plasterboard ceilings for 200mm diameter openings for ventilation grilles including extra hangers and support tee's etc.|No|4|||||14/11/2024 10:17:15|

528|33415|2|4|159| G|||Extra over skimmed plasterboard ceilings for 400 x 400mm duct for four way cassette AC unit including extra hangers and support tee's etc.|No|6|||||14/11/2024 04:35:48|

529|33410|2|4|159| H|||Extra over skimmed plasterboard ceilings for 1 200 x 600mm recessed light fittings including extra hangers and support tee's etc.|No|32|||||14/11/2024 04:29:49|

530|33413|2|4|159| J|||Extra over timber slatted ceilings for 275mm diameter openings for light fittings including extra hangers and support tee's etc.|No|11|||||15/11/2024 02:08:02|

531|33412|2|4|159| K|||Extra over timber slatted ceilings for 150mm diameter openings for ventilation grilles including extra hangers and support tee's etc.|No|10|||||14/11/2024 04:30:53|

532|33575|2|4|159| L|||Extra over timber slatted ceilings for 200mm diameter openings for ventilation grilles including extra hangers and support tee's etc.|No|4|||||14/11/2024 11:14:53|

533|33414|2|4|160| A|||Extra over timber slatted ceilings for 400 x 400mm duct for four way cassette AC unit including extra hangers and support tee's etc.|No|13|||||14/11/2024 04:35:16|

534|33411|2|4|160| B|||Extra over timber slatted ceilings for 1 200 x 600mm recessed light fittings including extra hangers and support tee's etc.|No|57|||||14/11/2024 04:30:41|

535|20781|2|4|161||39||BULKHEADS, ETC|H3|0.0|||||20/07/2023 02:08:24|

536|20782|2|4|161||||SUPPLEMENTARY PREAMBLES|H2|0.0|||||20/07/2023 02:08:24|

537|33405|2|4|161||54||All suspended bulkheads to be made up of Gypframe T37K or equivalent and approved concealed ceiling grid or equivalent approved.  The grid is to be made up as follows - 12.5mm/9mm/6.4mm Gyproc or equivalent and approved Rhinoboard fixed to Gypframe T32K or equivalent and approved cross tee using Gyproc or equivalent and approved sharp point screws 25mm at max 150mm centres. Gypframe T37K or equivalent and approved main tee to be installed at 1 200mm centres and suspended using Gyproc or equivalent and approved galvanised angle 25 x 25mm hangers at 1 200mm centres, fixed to steel purlins and main tees using Gyproc or equivalent and approved wafer head tek screws. Gypframe T32K or equivalent and approved cross tees installed at 400mm centres. Hangers to be maximum of 400mm from the perimeter wall. Apply Gyproc or equivalent and approved RhinoTape to all joints. Cover Gyproc or equivalent and approved RhinoTape with 1 layer of Gyproc or equivalent and approved Cretestone. Install Gypframe or equivalent and approved corner bead to all external corners||0.0|||||14/11/2024 04:23:05|

538|33406|2|4|161||6||Bulkheads shall comprise galvanised steel studding of 63.5mm top and bottom tracks with vertical studs at maximum 400mm centres, pop-riveted to the top and bottom tracks with similar additional vertical studs as necessary at abutments, ends, etc and covered as described with plasterboard or magnaboard as described screwed to studding with drywall screws at maximum 300mm centres. Boards shall be butt jointed and finished with tape and jointing compound and the whole finished with gypsum plaster trowelled to a smooth polished surface to the thickness recommended by the manufacturer||0.0|||||14/11/2024 04:23:05|

539|33407|2|4|161||6||Descriptions shall be deemed to include any additional studs at ends and intersections, corner beads, cornices at junctions with ceilings, jointing compound, tape, etc||0.0|||||14/11/2024 04:23:12|

540|20786|2|4|162||6||Flush suspended bulkheads|H2|0.0|||||20/07/2023 02:08:24|

541|33409|2|4|162| A|||Skimmed plastered bulkhead, 200mm high vertical shaped bulkhead formed of 12.5mm thick Gyproc Rhinoboard or equivalent approved panels with butt joints covered with patent fibatape and skimmed flush; corners covered with 25 x 25 x 1.6mm aluminium, screwed through to studs of pressed galvanised mild steel 63.5mm wide and including bracing of studs, channels, angles, all necessary supports, etc. complete as recommended by the manufacturer|m|15|||||14/11/2024 04:44:02|

542|33622|2|4|162| B|||Skimmed plastered bulkhead, 650mm high vertical shaped bulkhead formed of 12.5mm thick Gyproc Rhinoboard or equivalent approved panels with butt joints covered with patent fibatape and skimmed flush; corners covered with 25 x 25 x 1.6mm aluminium, screwed through to studs of pressed galvanised mild steel 63.5mm wide and including bracing of studs, channels, angles, all necessary supports, etc. complete as recommended by the manufacturer|m|25|||||15/11/2024 02:12:23|

543|33323|2|4|162||||CUBICLE PARTITIONING SYSTEM|H3|0.0|||||14/11/2024 04:26:13|

544|33324|2|4|162|||2.9.33|"Vitrex" or equivalent and approved, toilet partitioning with 20mm thick vitreous enamelled steel sheet faced particle board bonded panels and power coated aluminium edging and top rails including fixing components and standard ironmongery comprising indicator bolts, hinges, handles, locks, coat hooks, toilet roller holders, etc|H2|0.0|||||14/11/2024 04:26:22|

545|33343|2|4|162| C|||Partition, size 1 640mm wide x 2 100mm high complete with vertical joint|No|1|||||18/11/2024 05:15:01|

546|33606|2|4|162| D|||Partition, size 1 750mm wide x 2 100mm high complete with vertical joint|No|3|||||18/11/2024 05:15:05|

547|33607|2|4|162| E|||Partition, size 1 880mm wide x 2 100mm high complete with vertical joint|No|1|||||18/11/2024 05:15:11|

548|33608|2|4|162| F|||Partition, size 1 970mm wide x 2 100mm high complete with vertical joint|No|1|||||18/11/2024 05:15:16|

549|33345|2|4|162| G|||End Stiles 150mm wide x 2 100mm high complete with double telescopic stainless steel leg anchors in a standard arrangement|No|4|||||13/11/2024 12:30:33|

550|33346|2|4|163| A|||Wall Stiles 115mm wide x 2 100mm high complete with single telescopic stainless steel leg anchor in a standard arrangement|No|8|||||13/11/2024 12:29:50|

551|33347|2|4|163| B|||Doors size 762mm wide x 2 100mm high (Including top rail) and standard ironmongery (double indicator bolt and keep, coat hook, door butt hinges etc.)|No|6|||||18/11/2024 05:15:48|

552|33348|2|4|163| C|||Doors size 813mm wide x 2 100mm high (Including top rail) and standard ironmongery (double indicator bolt and keep, coat hook, door butt hinges etc.)|No|1|||||13/11/2024 12:38:53|

553|33331|2|4|163||92||FIXED PARTITIONS, ETC|H3|0.0|||||14/11/2024 04:26:43|

554|33332|2|4|163||||90mm Thick skimmed drywall partitions with 12,5mm thick board cladding on both sides and filled in with 25mm thick glasswool insulation in blanket form with a density of not less than 32kg/m², including gypsum skim plaster, tracks, rails, studs, etc|H2|0.0|||||14/11/2024 04:26:50|

555|33628|2|4|163| D|||Partitions 850mm high with bottom track fixed to top of aluminium shopfront frame and top track fixed to suspended ceiling tees|m|3|||||15/11/2024 02:35:35|

556|33629|2|4|163| E|||Extra over partition 850mm high for vertical abutment|No|2|||||15/11/2024 02:35:42|

557|33630|2|4|163| F|||Extra over partition 850mm high for corner|No|1|||||15/11/2024 02:35:53|

558|33592|2|4|163| G|||Partitions 1 750mm high with bottom track fixed to top of aluminium shopfront frame and top track fixed to suspended ceiling tees|m|4|||||15/11/2024 10:10:55|

559|33593|2|4|163| H|||Extra over partition 1 750mm high for vertical abutment|No|1|||||15/11/2024 10:11:14|

560|33594|2|4|163| J|||Extra over partition 1 750mm high for fair end|No|1|||||15/11/2024 10:11:31|

561|33333|2|4|163| K|||Partitions 2 200mm high with bottom track plugged and fixed to concrete floors and top track fixed to suspended ceiling tees|m|4|||||18/11/2024 05:17:02|

562|33334|2|4|163| L|||Extra over partition 2 200mm high for vertical abutment|No|6|||||14/11/2024 04:37:14|

563|33416|2|4|163| M|||Partitions 2 400mm high with bottom track plugged and fixed to concrete floors and top track fixed to suspended ceiling tees|m|5|||||18/11/2024 05:17:17|

564|33417|2|4|164| A|||Extra over partition 2 400mm high for vertical abutment|No|4|||||14/11/2024 04:37:20|

565|33420|2|4|164||||Extra over 90mm Thick skimmed drywall partitions with 12,5mm thick board cladding on both sides for powder coated (colour: satin black) aluminium shopfronts complete with subframes, butt joints, ironmongery, safety glass, sealing, etc , installed complete including additional studding, trimming, etc to drywall partitions|H2|0.0|||||14/11/2024 04:58:45|

566|33422|2|4|164| B|||Single aluminium door and frame, size 900 x 2 200mm high overall, with 100mm wide aluminium top rail, stiles and bottom rail, glazed with 8mm clear toughened glass with frosted/privacy film including one and a half pairs Dora "7320" or equivalent and approved stainless steel heavy duty butt hinges for aluminium door frame, one Dora "XS 4A" or equivalent and approved euro profile cylinder mortice lock set, one pair Dora "OGRO 8111" or equivalent and approved sleek design lever handle for euro profile lock and one Dora "DS77" or equivalent and approved floor or wall mounted door stop, complete (Type D02)|No|2|||||18/11/2024 05:18:09|

567|0|2|4|||||||0.0|||||11/06/2025 12:00:00|

568|15468|2|5|166||42||SECTION 2 |H1|0.0|||||20/07/2023 02:08:24|

569|15469|2|5|166||42||BILL NO 5|H1|0.0|||||15/11/2024 02:48:43|

570|15470|2|5|166||42||FLOOR COVERINGS, PLASTIC LININGS, ETC |H1|0.0|||||20/07/2023 02:08:24|

571|33649|2|5|166||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:26:09|

572|15471|2|5|166||||SUPPLEMENTARY PREAMBLES|H3|0.0|||||20/07/2023 02:08:24|

573|15472|2|5|166||||Fixing|H2|0.0|||||20/07/2023 02:08:24|

574|15473|2|5|166||||Floor coverings, wall linings, etc shall, where applicable, be fixed with adhesive as recommended by the manufacturers of the flooring, linings, etc||0.0|||||20/07/2023 02:08:24|

575|33428|2|5|166||94||Surface preparation, priming, curing, cleaning etc|H2|0.0|||||14/11/2024 05:16:55|

576|33429|2|5|166||94||Descriptions of the items below are deemed to include all necessary preparation, priming, mixing, curing, cleaning etc as prescribed by the manufacturers of the various products||0.0|||||14/11/2024 05:13:57|

577|33430|2|5|166||||Shop Drawings, Site Measurement and Samples|H2|0.0|||||14/11/2024 05:17:02|

578|33431|2|5|166||||The contractor shall prepare and apply at his own expense two sets of design and shop drawings and details of all fabricated work for approval, and no work shall be undertaken by the contractor until such approval has been obtained.  Before undertaking any manufacture, delivery or work on site, measurements shall be checked on site.  Samples of work may be asked by the Principal Agent for approval of workmanship, material types, etc., tenderers are to allow for this in their tendered amounts.||0.0|||||14/11/2024 05:14:06|

579|33423|2|5|167||||CARPETING|H3|0.0|||||14/11/2024 05:19:52|

580|33424|2|5|167||||500 x 500 x 5.0mm Belgotex "Accelerate Pivot" or equivalent and approved tufted multi-scroll loop pile carpet tile, with NexBac or equivalent and approved bitumen backing, including all necessary adhesives and laid in accordance with the manufacturer's instruction|H2|0.0|||||14/11/2024 05:25:24|

581|33425|2|5|167| A|||On floors|m2|245|||||19/11/2024 04:02:21|

582|33432|2|5|167||95||SKIRTINGS, NOSINGS, ETC|H3|0.0|||||14/11/2024 05:17:52|

583|33433|2|5|167||95||Sundries|H2|0.0|||||14/11/2024 05:17:59|

584|33434|2|5|167| B|95.4||"Kirk Marketing" or equivalent and approved 12mm aluminium straight edge trim (code: ASE120.BL) between carpet tiles and slate tiles, with matching base|m|33|||||14/11/2024 05:28:22|

585|0|2|5|||||||0.0|||||11/06/2025 12:00:00|

586|14989|2|6|169||||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

587|14990|2|6|169||46||BILL NO 6|H1|0.0|||||15/11/2024 02:48:47|

588|14991|2|6|169||61||IRONMONGERY |H1|0.0|||||20/07/2023 02:08:24|

589|33650|2|6|169||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:26:25|

590|25187|2|6|169||||SUPPLEMENTARY PREAMBLES|H3|0.0|||||20/07/2023 02:08:24|

591|25188|2|6|169||||Proprietary items|H2|0.0|||||20/07/2023 02:08:24|

592|25189|2|6|169||||Where applicable the manufacturers' names or product catalogue titles are given in sub-headings preceding the items  Prices are to be based on the specific products/articles specified. If tenderers wish to offer alternative products/articles for certain items, these items are to be clearly marked and the alternative specification given with supporting brochures, etc clarifying the features of the products/articles offered  On request returnable samples are to be provided to the principal agent for consideration||0.0|||||20/07/2023 02:08:24|

593|25190|2|6|170||||Finishes to ironmongery|H2|0.0|||||20/07/2023 02:08:24|

594|25191|2|6|170||||Where applicable finishes to ironmongery are indicated by suffixes in accordance with the following list:BS Satin bronze lacqueredCH Chromium plated SC Satin chromium plated SE Silver enamelled GE Grey enamelledAN Anodised natural AS Anodised silver AB Anodised bronze AG Anodised gold ABL Anodised black PB Polished brass PL Polished and lacquered PT Epoxy coated SD Sanded||0.0|||||27/07/2023 02:29:22|

595|33507|2|6|171||96||HINGES, BOLTS, ETC|H3|0.0|||||14/11/2024 06:33:41|

596|33508|2|6|171||96||"DORA" or equivalent and approved|H2|0.0|||||14/11/2024 06:34:04|

597|33509|2|6|171| A|96.1||"7320" Stainless steel heavy duty butt hinges suitable for timber frames|No|24|||||14/11/2024 06:43:45|

598|32166|2|6|171||||LOCKS|H3|0.0|||||16/07/2024 09:38:59|

599|33504|2|6|171||||"Ironmongery Warehouse" or equivalent and approved|H2|0.0|||||14/11/2024 06:40:18|

600|33459|2|6|171| B|||"IW2031" Ironware WC dead lock with 8mm follower|No|3|||||14/11/2024 06:09:02|

601|33455|2|6|171||||"DORA" or equivalent and approved|H2|0.0|||||14/11/2024 06:23:02|

602|33456|2|6|171| C|||"XS 4A" Euro profile escape function cylinder mortice lockset|No|5|||||14/11/2024 06:31:12|

603|33460|2|6|171||||HANDLES|H3|0.0|||||14/11/2024 06:09:02|

604|33461|2|6|171||||"DORA" or equivalent and approved|H2|0.0|||||14/11/2024 06:23:38|

605|33464|2|6|171| D|||"OGRO 8111" Lever pull handle for euro profile lock|No|10|||||14/11/2024 06:43:56|

606|33468|2|6|171||||DOOR CLOSERS|H3|0.0|||||14/11/2024 06:09:02|

607|33469|2|6|171||||"DORA" or equivalent and approved|H2|0.0|||||14/11/2024 06:23:28|

608|33470|2|6|171| E|||"TS 73 EMF" Surface mounted door closer with slide channel|No|8|||||19/11/2024 04:02:48|

609|33471|2|6|171||||LETTERS, NAMEPLATES, ETC|H3|0.0|||||14/11/2024 06:09:02|

610|33505|2|6|171||136||3mm Thick natural anodised aluminium nameplates with 36pt micro gramma bolt extended typeface lettering engraved in black|H2|0.0|||||14/11/2024 06:28:09|

611|33506|2|6|171| F|136.Q||Union (code: AL5021) or equivalent and approved emblem/nameplate size 150 x 150mm high for toilets with male, female or paraplegic sign|No|5|||||14/11/2024 06:28:40|

612|33477|2|6|171||||1.2mm Thick grade 304 polished stainless steel epoxy glued and screwed with countersunk stainless steel screws|H2|0.0|||||14/11/2024 06:09:03|

613|33478|2|6|171| G|||Kick plate size 900 x 300mm high|No|7|||||19/11/2024 04:02:34|

614|33481|2|6|172| A|||Push plate size 800 x 150mm high|No|6|||||19/11/2024 04:02:39|

615|33483|2|6|172||||SUNDRIES|H3|0.0|||||14/11/2024 06:09:03|

616|33510|2|6|172||||"DORA" or equivalent and approved|H2|0.0|||||14/11/2024 06:35:31|

617|33486|2|6|172| B|||"DS77" Floor or wall mounted door stop|No|8|||||14/11/2024 06:36:19|

618|33501|2|6|172||||"Ironmongery Warehouse" or equivalent and approved|H2|0.0|||||14/11/2024 06:38:03|

619|33489|2|6|172| C|||"IW1926" Ironware WC indicator set|No|3|||||14/11/2024 06:09:03|

620|33502|2|6|172| D|||"IW5034" Ironware door hook and buffer|No|6|||||14/11/2024 06:24:37|

621|32266|2|6|172||||BATHROOM FITTINGS|H3|0.0|||||16/07/2024 09:39:13|

622|33453|2|6|172||||"Lecico" or equivalent and approved|H2|0.0|||||14/11/2024 06:09:20|

623|33454|2|6|172| E|||Vitreous china urinal separator partition (code: ATLURISEP0630UE), size 150mm wide x 320mm deep x 630mm high, including fixation set and fixing to brick walls with necessary plugs and installation screws as per the manufacturers specifications, complete|No|1|||||14/11/2024 06:07:55|

624|32267|2|6|172||||"Franke" or equivalent and approved|H2|0.0|||||14/11/2024 06:05:11|

625|32269|2|6|172| F|||"Stratos STRX672" Grade 304 1,2/1,5mm thick 18/10 satin stainless steel double toilet paper roll holder (code: 359716), size 304 x 156 x 140mm, plugged and screwed to wall with stainless steel screws, complete|No|10|||||16/07/2024 09:39:13|

626|32268|2|6|172| G|||"Stratos STRX618" Grade 304 1,2/1,5mm thick 18/10 satin stainless steel soap dispenser (code: 359705), size 304 x 100 x 134mm deep, plugged and screwed to wall with stainless steel screws, complete|No|8|||||16/07/2024 09:39:13|

627|32270|2|6|172| H|||"Chronos BS600P" Grade 304 1,2/1,5mm thick 18/10 satin stainless steel paper towel dispenser (code: 359790), size 438 x 290 x 115mm, plugged and screwed to wall with stainless steel screws, complete|No|2|||||16/07/2024 09:39:13|

628|33452|2|6|172| J|100.39||Rodan "RODX605" wall mounted brushed stainless steel waste paper bin 355 x 460 x 168mm (Code: 2000090061)|No|5|||||14/11/2024 06:07:32|

629|33498|2|6|173| A|||18/10 stainless steel grab rail 750 x 260mm wide (code: 2510012) including cover plates and fixing to walls with mounting bolts as supplied, complete|No|3|||||14/11/2024 06:42:02|

630|33500|2|6|173||||"Dyson" or equivalent and approved|H2|0.0|||||14/11/2024 06:12:39|

631|33496|2|6|173| B|100.40||’’Airblade V’’ Wall mounted stainless steel hand dryer overall size 100 x 234 x 394mm high with and including ABS plastic casing, Hepa filter and sensor operation system, plugged and screwed to wall with stainless steel screws, complete|No|3|||||14/11/2024 06:42:12|

632|0|2|6|||||||0.0|||||11/06/2025 12:00:00|

633|14848|2|7|175||||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

634|14849|2|7|175||46||BILL NO 7|H1|0.0|||||15/11/2024 02:49:10|

635|14850|2|7|175||46||METALWORK |H1|0.0|||||20/07/2023 02:08:24|

636|33651|2|7|175||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:26:29|

637|21353|2|7|175||||SUPPLEMENTARY PREAMBLES|H3|0.0|||||20/07/2023 02:08:24|

638|21354|2|7|175||||Descriptions of bolts, anchors, etc|H2|0.0|||||20/07/2023 02:08:24|

639|21355|2|7|175||||Descriptions of bolts shall be deemed to include nuts and washers||0.0|||||20/07/2023 02:08:24|

640|21356|2|7|175||||Descriptions of expansion anchors and bolts and chemical anchors and bolts shall be deemed to include nuts, washers and mortices in brickwork or concrete||0.0|||||20/07/2023 02:08:24|

641|21357|2|7|175||||Items described as "holed for bolt(s)" shall be deemed to exclude the bolts unless otherwise described||0.0|||||20/07/2023 02:08:24|

642|21358|2|7|175||||Items described as "plugged" shall be deemed to include screwing to fibre, plastic or metal plugs at not exceeding 600mm centres||0.0|||||20/07/2023 02:08:24|

643|21359|2|7|175||||Aluminium doors, windows, etc|H2|0.0|||||20/07/2023 02:08:24|

644|21360|2|7|175||||The following wind pressures must be allowed for in the designs.  Maximum external wind pressure. 1.0 kN/m² Maximum internal wind pressure. 0.45kN/m²||0.0|||||20/07/2023 02:08:24|

645|21361|2|7|176||||3. A powder guarantee of not less than 15 years issued by the powder manufacturer. The specific conditions contained in this guarantee shall form part of the powder coating process  4. A Certificate of Conformance confirming that glazing has been installed in accordance with SANS 0137, ensuring that safety glazing materials have been installed in the mandatory areas and that each individual pane of safety glazing materials has been permanently marked  5. A warranty from the manufacturer of the laminated safety glass and/or hermetically sealed glazing units guaranteeing the products against delamination and colour degradation for a period of not less than five years||0.0|||||20/07/2023 02:08:24|

646|21362|2|7|176||||Descriptions of aluminium doors, windows and shopfronts shall be deemed to include all necessary sealing at reveals with approved silicone sealant, as may be required||0.0|||||20/07/2023 02:08:24|

647|32085|2|7|176||||GALVANISED MILD STEEL|H3|0.0|||||16/07/2024 03:18:40|

648|32670|2|7|176||||Galvanised mild steel balustrades, installed in accordance to the manufacturers instructions, including fixing, bolts, etc, complete |H2|0.0|||||19/07/2024 10:49:04|

649|32671|2|7|176| A|||1 000mm high overall galvanised mild steel balustrades consisting of 50mm diameter x 4mm thick galvanised mild steel vertical balusters at approximately 900mm c/c with holes to be pre drilled at 300mm c/c maximum, 50mm diameter x 4mm thick galvanised mild steel continuous hand rail to top of balusters and 38mm diameter x 4mm thick galvanised mild steel horizontal rails at 300mm c/c maximum to fit into pre drilled holes, all welded together and epoxy fixed into concrete floor with chemical anchor bolts including galvanised mild steel fixing plate and galvanised mild steel escutcheon, complete|m|9|||||18/11/2024 05:30:58|

650|32701|2|7|176| B|||Extra over for 90 degree bend|No|1|||||19/07/2024 05:54:32|

651|14862|2|7|177||48||STAINLESS STEEL AND ALUMINIUM CORNER PROTECTION|H3|0.0|||||14/11/2024 06:50:50|

652|14863|2|7|177||139||Corner protectors|H2|0.0|||||14/11/2024 06:51:00|

653|29240|2|7|177| A|||30 x 30 "Kirk Marketing" (grade 316) or equivalent and approved tile-in corner protectors STICP 300 round corner, to vertical corners, 2 200mm high, nailed on both sides|No|3|||||18/11/2024 05:31:53|

654|19411|2|7|177| B|||Ditto, but 2 400mm high|No|14|||||14/11/2024 07:24:42|

655|22901|2|7|177| C|||"Kirk Marketing" or equivalent and approved 12mm aluminium vertical square edge trim, plugged (code: ASQE120.BL)|m|26|||||14/11/2024 07:08:58|

656|29200|2|7|177| D|||"Kirk Marketing" or equivalent and approved 12mm aluminium horizontal straight edge trim (code: ASE120.BL)|m|16|||||14/11/2024 07:06:39|

657|14962|2|7|177||||ALUMINIUM WINDOWS, DOORS, ETC|H3|0.0|||||20/07/2023 02:08:24|

658|33511|2|7|177||110||INTERNAL SHOPFRONTS|H3|0.0|||||14/11/2024 07:21:18|

659|33513|2|7|177||110||"Wispeco" or equivalent and approved powder coated aluminium framed beaded shopfronts (Colour: satin black) with rubber gaskets or square glazing beads, transoms, mullions, 8mm clear toughened glass and privacy film, continuous rubber/brush seals and stainless steel pivot-out stays and levers including ironmongery, waterproofing angles and membranes and fixing and fitting to partitions, brickwork, concrete or steel as per manufactures specifications (Refer to architects drawing no. A501)|H2|0.0|||||14/11/2024 07:23:05|

660|33623|2|7|177| E|||Purpose made shopfront, overall size 4 120 x 1 400mm high with three fixed panels|No|1|||||15/11/2024 02:14:19|

661|33624|2|7|177| F|||Purpose made shopfront, overall size 4 300 x 1 400mm high with four fixed panels|No|1|||||15/11/2024 02:14:45|

662|33551|2|7|177| G|||Purpose made shopfront, overall size 1 100 x 2 200mm high with one fixed panel|No|1|||||14/11/2024 09:40:23|

663|33512|2|7|177| H|||Purpose made shopfront, overall size 1 460 x 2 400mm high with one fixed panel|No|1|||||14/11/2024 07:36:45|

664|33587|2|7|178| A|||Purpose made shopfront, overall size 4 300 x 2 400mm high with four fixed panels|No|1|||||15/11/2024 09:47:29|

665|33588|2|7|178| B|||Purpose made shopfront, overall size 4 860 x 2 400mm high with four fixed panels|No|1|||||15/11/2024 09:48:00|

666|33514|2|7|178||110||INTERNAL SHOPFRONTS WITH DOORS|H3|0.0|||||14/11/2024 07:22:11|

667|33515|2|7|178||110||"Wispeco" or equivalent and approved powder coated aluminium framed beaded shopfronts (Colour: satin black) with rubber gaskets or square glazing beads, transoms, mullions, 8mm clear toughened glass and privacy film, continuous rubber/brush seals and stainless steel pivot-out stays and levers including ironmongery, waterproofing angles and membranes and fixing and fitting to partitions, brickwork, concrete or steel as per manufactures specifications (Refer to architects drawing no. A501)|H2|0.0|||||14/11/2024 07:23:12|

668|33595|2|7|178| C|110.42||Purpose made shopfront, 2 900 x 2 200mm high with three fixed panels and one single aluminium door and frame, size 900 x 2 200mm high overall, with 100mm wide aluminium top rail, stiles and bottom rail, glazed with 8mm clear toughened glass with frosted/privacy film including one and a half pairs Dora "7320" or equivalent and approved stainless steel heavy duty butt hinges for aluminium door frame, one Dora "XS 4A" or equivalent and approved euro profile cylinder mortise lock set, one pair Dora "OGRO 8111" or equivalent and approved sleek design lever handle for euro profile lock and one Dora "DS77" or equivalent and approved floor or wall mounted door stop, complete|No|1|||||15/11/2024 10:14:02|

669|33589|2|7|178| D|110.42||Purpose made shopfront, 3 400 x 2 400mm high with three fixed panels and one single aluminium door and frame, size 900 x 2 200mm high overall, with 100mm wide aluminium top rail, stiles and bottom rail, glazed with 8mm clear toughened glass with frosted/privacy film including one and a half pairs Dora "7320" or equivalent and approved stainless steel heavy duty butt hinges for aluminium door frame, one Dora "XS 4A" or equivalent and approved euro profile cylinder mortise lock set, one pair Dora "OGRO 8111" or equivalent and approved sleek design lever handle for euro profile lock and one Dora "DS77" or equivalent and approved floor or wall mounted door stop, complete|No|1|||||15/11/2024 09:49:07|

670|33625|2|7|179| A|110.42||Purpose made shopfront, 4 451 x 2 400mm high with four fixed panels and one single aluminium door and frame, size 900 x 2 200mm high overall, with 100mm wide aluminium top rail, stiles and bottom rail, glazed with 8mm clear toughened glass with frosted/privacy film including one and a half pairs Dora "7320" or equivalent and approved stainless steel heavy duty butt hinges for aluminium door frame, one Dora "XS 4A" or equivalent and approved euro profile cylinder mortise lock set, one pair Dora "OGRO 8111" or equivalent and approved sleek design lever handle for euro profile lock and one Dora "DS77" or equivalent and approved floor or wall mounted door stop, complete|No|1|||||15/11/2024 02:16:11|

671|33516|2|7|179| B|110.42||Purpose made shopfront, 5 400 x 2 400mm high with five fixed panels and one single aluminium door and frame, size 900 x 2 200mm high overall, with 100mm wide aluminium top rail, stiles and bottom rail, glazed with 8mm clear toughened glass with frosted/privacy film including one and a half pairs Dora "7320" or equivalent and approved stainless steel heavy duty butt hinges for aluminium door frame, one Dora "XS 4A" or equivalent and approved euro profile cylinder mortise lock set, one pair Dora "OGRO 8111" or equivalent and approved sleek design lever handle for euro profile lock and one Dora "DS77" or equivalent and approved floor or wall mounted door stop, complete|No|1|||||14/11/2024 07:37:48|

672|33590|2|7|179| C|110.42||Purpose made shopfront, 8 500 x 2 400mm high with seven fixed panels and two single aluminium doors and frame, size 900 x 2 200mm high overall, with 100mm wide aluminium top rail, stiles and bottom rail, glazed with 8mm clear toughened glass with frosted/privacy film including one and a half pairs Dora "7320" or equivalent and approved stainless steel heavy duty butt hinges per door for aluminium door frame, one Dora "XS 4A" or equivalent and approved euro profile cylinder mortice lock set per door, one pair Dora "OGRO 8111" or equivalent and approved sleek design lever handle for euro profile lock per door and one Dora "DS77" or equivalent and approved floor or wall mounted door stop per door, complete|No|1|||||15/11/2024 09:51:33|

673|33631|2|7|180| A|110.42||Purpose made L-shaped shopfront, 2 350 x 2 200mm high with two fixed panels and one single aluminium door and frame, size 900 x 2 200mm high overall, with 100mm wide aluminium top rail, stiles and bottom rail, glazed with 8mm clear toughened glass with frosted/privacy film including one and a half pairs Dora "7320" or equivalent and approved stainless steel heavy duty butt hinges for aluminium door frame, one Dora "XS 4A" or equivalent and approved euro profile cylinder mortise lock set, one pair Dora "OGRO 8111" or equivalent and approved sleek design lever handle for euro profile lock and one Dora "DS77" or equivalent and approved floor or wall mounted door stop, complete|No|1|||||15/11/2024 02:40:00|

674|33518|2|7|180| B|||Double aluminium door and frame, size 1 650 x 2 400mm high overall, with 45mm wide aluminium top rail and stiles and 100mm wide bottom rail, glazed with 8mm clear toughened glass with frosted/privacy film including one and a half pairs Dora "7320" or equivalent and approved stainless steel heavy duty butt hinges per door leaf for aluminium door frame, one Dora "TS 93" or equivalent and approved surface mounted door closer with cam action and slide channel per door leaf, one Dora "XS 4A" or equivalent and approved euro profile cylinder mortice lock set per door leaf, two pairs Dora "OGRO 8111" or equivalent and approved sleek design lever handle for euro profile lock and one Dora "DS77" or equivalent and approved floor or wall mounted door stop per door leaf, complete (Type D03)|No|4|||||14/11/2024 07:35:43|

675|14976|2|7|180||||ALUMINIUM LOUVRE UNITS|H3|0.0|||||20/07/2023 02:08:24|

676|14977|2|7|180||||Trox or equivalent and approved natural anodised fixed louvre units screwed into timber frames|H2|0.0|||||18/11/2024 05:34:18|

677|23085|2|7|180| C|||Standard louvre unit type AGS-T, 750 x 150mm high fixed into openings in timber doors|No|6|||||14/11/2024 06:48:39|

678|0|2|7|||||||0.0|||||11/06/2025 12:00:00|

679|14822|2|8|182||||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

680|14823|2|8|182||52||BILL NO 8|H1|0.0|||||15/11/2024 02:49:14|

681|14824|2|8|182||52||PLASTERING |H1|0.0|||||20/07/2023 02:08:24|

682|33652|2|8|182||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:26:36|

683|19448|2|8|182||147||SCREEDS, ETC |H3|0.0|||||20/07/2023 02:08:24|

684|25481|2|8|182||147||1:3 Cement screed on concrete |H2|0.0|||||20/07/2023 02:08:24|

685|32547|2|8|182| A|||25mm Thick to concrete floors|m2|12|||||19/11/2024 04:45:06|

686|33436|2|8|182||107||SELF LEVELLING SCREEDS|H3|0.0|||||14/11/2024 05:16:10|

687|33437|2|8|182||||Prepare and apply 3mm ITE F30 or equivalent and approved self levelling screeds, to be done with gauge or rolling pin for smoothest finish possible with and including ITE or equivalent and approved slurry (carpet tile measured elsewhere) to|H2|0.0|||||18/11/2024 05:35:24|

688|33438|2|8|182| B|||Existing floors in preparation for new carpet tiles|m2|245|||||14/11/2024 08:10:11|

689|33530|2|8|182||52||INTERNAL PLASTER TO EXISTING|H3|0.0|||||14/11/2024 08:11:46|

690|33531|2|8|182||148||One coat cement plaster to brickwork (part on concrete) to|H2|0.0|||||14/11/2024 08:11:46|

691|33532|2|8|182| C|148.D||Walls |m2|134|||||14/11/2024 08:11:46|

692|33533|2|8|182| D|148.E||Narrow widths not exceeding 300mm wide |m2|6|||||14/11/2024 08:11:46|

693|33553|2|8|182||||One coat cement plaster to concrete to |H2|0.0|||||14/11/2024 09:42:26|

694|33552|2|8|182| E|78.G||Isolated and projecting columns |m2|33|||||14/11/2024 09:41:51|

695|33554|2|8|182| F|78.G||Sides and soffits of beams|m2|20|||||14/11/2024 09:42:40|

696|14838|2|8|183||148||INTERNAL PLASTER TO NEW|H3|0.0|||||20/07/2023 02:08:24|

697|14839|2|8|183||148||One coat cement plaster to brickwork (part on concrete) to|H2|0.0|||||20/07/2023 02:08:24|

698|14840|2|8|183| A|148.D||Walls |m2|5|||||20/07/2023 02:08:24|

699|14841|2|8|183| B|148.E||Narrow widths not exceeding 300mm wide |m2|0.3|||||20/07/2023 02:08:24|

700|0|2|8|||||||0.0|||||11/06/2025 12:00:00|

701|14770|2|9|185||||SECTION 2|H1|0.0|||||17/07/2024 11:22:41|

702|14771|2|9|185||53||BILL NO 9|H1|0.0|||||15/11/2024 02:49:20|

703|14772|2|9|185||53||TILING |H1|0.0|||||20/07/2023 02:08:24|

704|33653|2|9|185||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:26:49|

705|19464|2|9|185||||SUPPLEMENTARY PREAMBLES|H3|0.0|||||20/07/2023 02:08:24|

706|19465|2|9|185||186||Descriptions|H2|0.0|||||20/07/2023 02:08:24|

707|19466|2|9|185||186||Descriptions of tiling shall be deemed to include for symmetrical arrangement of tiling with cutting along both sides of panels and for all straight cutting||0.0|||||20/07/2023 02:08:24|

708|19467|2|9|185||186||Descriptions of tiling shall be deemed to include for soft grouted joints at positions of joints in the substructure or at centres in both directions as recommended by the tile manufacturers or which represents good practice||0.0|||||20/07/2023 02:08:24|

709|19468|2|9|185||||Fixing|H2|0.0|||||20/07/2023 02:08:24|

710|19469|2|9|185||||Ceramic, porcelain and slate tiles are to be fixed and grouted with suitable adhesives and grouts from the range of products as recommended by the manufacturer of the tiles||0.0|||||20/07/2023 02:08:24|

711|19470|2|9|185||||Preparation: The background must be clean, dry, firm and free of dust or loose particles before keycoat is applied.||0.0|||||20/07/2023 02:08:24|

712|14773|2|9|186||53||WALL TILING |H3|0.0|||||20/07/2023 02:08:24|

713|33540|2|9|186||||297 x 297mm "Italtile Kitkat" or equivalent and approved dark porcelain mosaic tile sheets fixed to internal cement plastered walls (plaster measured elsewhere) with Goldstar 6 or equivalent and approved fast setting adhesive with Talbond or equivalent and approved additive fully applied behind tiles and joints filled with black epoxy tile grout with fungicidal additive to|H2|0.0|||||18/11/2024 05:36:14|

714|33548|2|9|186| A|||Walls in splashbacks|m2|11|||||14/11/2024 09:18:39|

715|24359|2|9|186||||300 x 300 x 6mm "Italtile Project" or equivalent and approved charcoal unglazed porcelain mosaic tile sheets fixed to internal cement plastered walls (plaster measured elsewhere) with Goldstar 6 or equivalent and approved fast setting adhesive with Talbond or equivalent and approved additive fully applied behind tiles and joints filled with black epoxy tile grout with fungicidal additive to|H2|0.0|||||18/11/2024 05:36:36|

716|24360|2|9|186| B|||Walls|m2|150|||||20/07/2023 02:08:24|

717|24362|2|9|186| C|||Ditto, but in narrow widths not exceeding 300mm wide|m2|8|||||20/07/2023 02:08:24|

718|32048|2|9|186||55||Sundries|H2|0.0|||||16/07/2024 02:24:56|

719|33441|2|9|186| D|54.A||Keycote consisting of 1 part TAL keycoat to 2 parts cement (by volume) to walls|m2|169|||||14/11/2024 05:32:29|

720|33545|2|9|186| E|||Fair cutting around waste pipes not exceeding 50mm diameter|No|10|||||14/11/2024 09:07:41|

721|33544|2|9|186| F|||Fair cutting around WC 110mm outlet pipe |No|10|||||14/11/2024 09:07:37|

722|32049|2|9|186| G|||Fair cutting around circular wash hand basin|No|2|||||17/07/2024 11:22:24|

723|33614|2|9|186| H|||Fair cutting around wall mounted basin mixer tap|No|6|||||15/11/2024 12:27:15|

724|32050|2|9|186| J|||Fair cutting around urinal including silicone sealant |No|2|||||17/07/2024 11:22:25|

725|14796|2|9|187||54||FLOOR TILES |H3|0.0|||||20/07/2023 02:08:24|

726|14797|2|9|187||54||SUPPLEMENTARY PREAMBLES|H2|0.0|||||20/07/2023 02:08:24|

727|33443|2|9|187||125||Tiles on surfacebedsThe existing surface must be clean, dry, firm and free of dust, loose particles or other contaminants before the Keycoat is applied.Key the tiled areas with a slurry coat consisting of 1 part Tal or equivalent and approved Keycoat to 2 parts cement (by volume) prior to the application of the tiling adhesive.Adhesive:	Tal Goldstar 6 or equivalent and 		approved, mixed with TalBond or 		equal and approved (in lieu of water) Joints:		3 to 10mm maximumGrout:		Tal Wall & Floor - (colour by 		            Architect) or equal and approved		No traffic (including foot traffic) allowed within 8 hours after the new tiles have been laid and grouted.-------------||0.0|||||14/11/2024 05:37:10|

728|33444|2|9|187||54||Tiles on suspended slabsThe existing surface must be clean, dry, firm and free of dust, loose particles or other contaminants before the Keycoat is applied.Key the tiled areas with a slurry coat consisting of 1 part Tal or equal and approved Keycoat to 2 parts cement (by volume) prior to the application of the tiling adhesive.Adhesive:Tal Goldflex Ultra or equal and 		approved, mixed with TalBond or 		equal and approved (in lieu of water) Joints:	3 to 10mm maximumGrout:	Tal Wall & Floor - (colour by 		            	Architect) or equal and 			approved		No traffic (including foot traffic) allowed within 8 hours after the new tiles have been laid and grouted.-------------||0.0|||||14/11/2024 05:37:22|

729|33536|2|9|188||125||300 x 300 x 6mm "Italtile" or equivalent and approved charcoal unglazed porcelain mosaic tile sheets on prepared floors fixed with TAL Goldstar - 6HR or equivalent and approved adhesive with joints pointed in black anti-bacterial and chemical resistant epoxy grout smooth slightly concave in 3mm wide joints on|H2|0.0|||||15/11/2024 02:58:35|

730|33537|2|9|188| A|54.A||Floors and landings|m2|8|||||14/11/2024 08:52:33|

731|33445|2|9|188||125||600 x 600mm "Master Stone" or equivalent and approved african blue large format slate tiles on prepared floors fixed with TAL Goldstar - 6HR or equivalent and approved adhesive with joints pointed in grey anti-bacterial and chemical resistant epoxy grout smooth slightly concave in 10mm wide joints on|H2|0.0|||||15/11/2024 02:58:30|

732|31946|2|9|188| B|54.A||Floors and landings|m2|79|||||19/11/2024 04:45:23|

733|25443|2|9|188| C|||Floors in patches to replace damaged tiles|m2|3|||||19/11/2024 04:45:27|

734|33555|2|9|188| D|54.A||Top and sides of upstand beam|m2|5|||||19/11/2024 04:45:59|

735|31947|2|9|188| E|55.A||Cut tile skirting 100mm high including silicone sealant between skirting and floor tile|m|85|||||19/11/2024 04:46:03|

736|33612|2|9|188||125||300 x 300 x 6mm "Italtile" or equivalent and approved charcoal unglazed porcelain mosaic tile sheets on prepared floors fixed with TAL Goldflex Ultra or equal and approved rapid set adhesive to floors with joints pointed in black anti-bacterial and chemical resistant epoxy grout smooth slightly concave in 3mm wide joints on|H2|0.0|||||15/11/2024 02:58:53|

737|33613|2|9|188| F|54.A||Floors and landings|m2|36|||||19/11/2024 04:46:09|

738|33446|2|9|188||125||600 x 600mm "Master Stone" or equivalent and approved african blue large format slate tiles on prepared floors fixed with TAL Goldflex Ultra or equal and approved rapid set adhesive to floors with joints pointed in grey anti-bacterial and chemical resistant epoxy grout smooth slightly concave in 10mm wide joints on|H2|0.0|||||14/11/2024 09:08:51|

739|33546|2|9|188| G|||Floors in patches to replace damaged tiles|m2|2|||||19/11/2024 04:46:14|

740|16130|2|9|188| H|55.A||Cut tile skirting 100mm high including silicone sealant between skirting and floor tile|m|65|||||19/11/2024 04:46:17|

741|20725|2|9|189||||MOVEMENT JOINTS|H2|0.0|||||20/07/2023 02:08:24|

742|20726|2|9|189| A|||5mm Wide open joint in tiling filed with and including polypropelene backing cord, treated with approved primer and TAL Goldstar Sealmaster 1000 or equivalent and approved polyurethane sealant|m|53|||||14/11/2024 09:10:46|

743|33547|2|9|189| B|||10mm Wide open joint in tiling filed with and including polypropelene backing cord, treated with approved primer and TAL Goldstar Sealmaster 1000 or equivalent and approved polyurethane sealant|m|71|||||19/11/2024 04:46:20|

744|14809|2|9|189||55||SUNDRIES|H2|0.0|||||20/07/2023 02:08:24|

745|19489|2|9|189| C|||Hammer test existing slate floor tiles for all loose and hollow tiles|m2|51|||||19/11/2024 04:46:25|

746|26590|2|9|189| D|||Clean off and polish existing slate floor tiles of grease, oil, grime and dirt etc. by machine polishing and resealing tile afterwards|m2|51|||||19/11/2024 04:46:29|

747|26591|2|9|189| E|||Chop out and remove all hollow sounding cracked, broken, chipped or otherwise damaged tiles clean off background adhesive and apply TAL or equivalent and approved Keycoat slurry before filling it with TAL Goldstar 6 or equivalent and approved Adhesive to prepare for new tile (new tile measured above) (provisional allowance)|m2|5|||||19/11/2024 04:46:33|

748|29226|2|9|189| F|54.A||Keycote consisting of 1 part TAL keycoat to 2 parts cement (by volume) to floors|m2|122|||||31/07/2023 12:18:57|

749|33442|2|9|189| G|95.4||"Kirk Marketing" or equivalent and approved 12mm aluminium straight edge trim (code: ASE120.BL) to edge of slate tiles, with matching base|m|25|||||14/11/2024 05:33:11|

750|14814|2|9|189| H|||Fair cutting around WC pedistals|No|10|||||14/11/2024 05:33:18|

751|0|2|9|||||||0.0|||||11/06/2025 12:00:00|

752|14582|2|10|191||||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

753|14583|2|10|191||57||BILL NO 10|H1|0.0|||||15/11/2024 02:49:25|

754|14584|2|10|191||57||PLUMBING AND DRAINAGE |H1|0.0|||||20/07/2023 02:08:24|

755|33654|2|10|191||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:26:54|

756|25151|2|10|191||153||SUPPLEMENTARY PREAMBLES |H3|0.0|||||20/07/2023 02:08:24|

757|25152|2|10|191||76||Sealing of edges|H2|0.0|||||20/07/2023 02:08:24|

758|25153|2|10|191||76||Outer edges of sinks, basins, baths, urinals, etc are to be sealed against adjacent surfaces with approved silicone||0.0|||||20/07/2023 02:08:24|

759|25154|2|10|191||76||uPVC pipes and fittings|H2|0.0|||||20/07/2023 02:08:24|

760|25155|2|10|191||76||Sewer and drainage pipes and fittings shall be jointed and sealed with butyl rubber rings  Soil, waste and vent pipes and fittings shall be solvent weld jointed or sealed with butyl rubber rings||0.0|||||20/07/2023 02:08:24|

761|25156|2|10|191||77||uPVC pressure pipes and fittings|H2|0.0|||||20/07/2023 02:08:24|

762|25157|2|10|191||77||Pipes of 50mm diameter and smaller shall be plain ended with solvent welded uPVC loose sockets and fittings  Pipes of 63mm diameter and greater shall have sockets and spigots with push-in type integral rubber ring joints. Bends shall be uPVC and all other fittings shall be cast iron, all with similar push-in type joints||0.0|||||20/07/2023 02:08:24|

763|25158|2|10|192||77||Copper pipes|H2|0.0|||||20/07/2023 02:08:24|

764|25159|2|10|192||77||Pipes shall be hard drawn and half-hard "Maksal" pipes of the class described. Class 0 (thin walled hard drawn) pipes shall not be bent. Class 1 (thin walled half-hard), Class 2 (half-hard) and Class 3 (heavy walled half-hard) pipes shall only be bent with benders with inner and outer formers. Fittings to copper waste, vent and anti-syphon pipes, capillary solder fittings and compression fittings shall be "Cobra Watertech" type or equivalent and approved. Capillary solder fittings shall comply with ISO 2016||0.0|||||18/11/2024 05:40:00|

765|25160|2|10|192||77||Copper pipes are to be installed in accordance with the latest revision of the Code of Practice for Copper Plumbing soldering techniques. Flux, solder, etc to be strictly in accordance with the manufacturer's requirements with special attention to copper flux composition||0.0|||||20/07/2023 02:08:24|

766|25161|2|10|192||78||Reducing fittings|H2|0.0|||||20/07/2023 02:08:24|

767|25162|2|10|192||78||Where fittings have reducing ends or branches they are described as "reducing" and only the largest end or branch size is given. Should the contractor wish to use other fittings and bushes or reducers he may do so on the understanding that no claim in this regard will be entertained||0.0|||||20/07/2023 02:08:24|

768|25163|2|10|192||78||Fixing of pipes|H2|0.0|||||20/07/2023 02:08:24|

769|25164|2|10|192||78||Unless specifically otherwise stated, descriptions of pipes shall be deemed to include fixing to walls, etc, casting in, building in or suspending not exceeding 1m below suspension level||0.0|||||20/07/2023 02:08:24|

770|25165|2|10|192||79||General|H2|0.0|||||20/07/2023 02:08:24|

771|25166|2|10|192||79||Descriptions of service pipes and flexible connecting pipes shall be deemed to include connections to taps, cisterns, etc and to steel pipes (adaptors for connections to copper pipes, etc are given separately)||0.0|||||20/07/2023 02:08:24|

772|25167|2|10|192||79||Descriptions of WC pans, slop hoppers, etc shall be deemed to include for joints to soil pipes (pan connectors are separately measured)||0.0|||||20/07/2023 02:08:24|

773|25168|2|10|192||153||All pipe diameters are internal pipe diameters||0.0|||||20/07/2023 02:08:24|

774|14585|2|10|193||58||SANITARY FITTINGS |H3|0.0|||||20/07/2023 02:08:24|

775|14586|2|10|193||78||"Franke" or equivalent and approved stainless steel (grade 304 18/10)|H2|0.0|||||14/11/2024 08:18:53|

776|29414|2|10|193| A|78.D||"Nouveau NVN621" Double bowl drop in sink, size 1 160mm long x 460mm wide overall with two 340 x 370 x 149mm deep bowls, including 38mm waste fitting, 90mm PVC waste to drain waste outlet, basket waste kit for 90mm outlets and Spazio F/1 plumbing kit (code: 301152), accordance with the manufacturer's instructions, complete|No|2|||||14/11/2024 08:22:07|

777|26861|2|10|193||||"Duravit" or equivalent or approved|H2|0.0|||||14/11/2024 08:22:38|

778|26862|2|10|193| B|||"Durastyle" Close coupled floor standing toilet (Colour: White) with rimless technology and integrated cistern with dual flush system (3/6 litres) including soft closing toilet seat and cover and floor fixing kit, installed complete|No|10|||||14/11/2024 08:31:17|

779|26858|2|10|193||78||"Grohe" or equivalent and approved|H2|0.0|||||14/11/2024 08:34:07|

780|29359|2|10|193| C|78.G||"Bau" ceramic wall hung basin (code: GRO-39440000) with overflow, size 553mm x 386mm with centre hole, bolted to wall with two 10mm bolts (code: RAW R-S1-KPU141), installed complete.|No|3|||||19/11/2024 04:46:42|

781|26860|2|10|193| D|||"Bau" Ceramic urinal concealed inlet including fixation set with flush volume of 1lt (Code: G-39438000), Rapido U roughest (Code: 38338000) with Tectron skate infra-red electronic final installation set with mains power 230v (Code: 37321SD1)|No|2|||||20/07/2023 02:08:24|

782|14599|2|10|193||59||TRAPS, WASTES, ETC |H3|0.0|||||20/07/2023 02:08:24|

783|14600|2|10|193||79||"Cobra Watertech" or equivalent and approved|H2|0.0|||||14/11/2024 08:34:54|

784|24788|2|10|193| E|79.B||32mm Chrome plated slotted basin waste union with 62mm dia. flange, 80mm shank and plug|No|3|||||14/11/2024 08:39:08|

785|26095|2|10|193| F|6.D||40mm Chrome plated heavy pattern sink waste union with backnut, chain and stay (code: 317-40)|No|2|||||20/07/2023 02:08:24|

786|29360|2|10|193| G|79.B||40mm Chrome plated deep seal bottle trap with MI outlet (code: 345/40)|No|12|||||02/08/2023 10:02:19|

787|14613|2|10|194||79||TAPS, VALVES, ETC|H3|0.0|||||20/07/2023 02:08:24|

788|14614|2|10|194||79||"Cobra Watertech" or equivalent and approved|H2|0.0|||||14/11/2024 08:37:12|

789|32775|2|10|194| A|160.Q||15mm "Cobratron" chrome plated electronic spout single temperature basin tap with sensor including water saving feature (flow rate to be set at 6L/min) and 230V connection to mains, complete|No|8|||||14/11/2024 08:46:26|

790|15770|2|10|194| B|79.G||15mm "Stella" chrome plated deck mounted sink mixer with "swan neck" swivel spout outlet, ceramic disc head parts, bent inlet connections and wall flanges including water saving feature (flow rate to be set at 6L/min), complete|No|2|||||14/11/2024 08:48:26|

791|33535|2|10|194| C|||15mm Angle regulating valve with 350mm stainless steel flexible hose connector|No|22|||||14/11/2024 08:49:06|

792|0|2|10|||||||0.0|||||11/06/2025 12:00:00|

793|14574|2|11|196||||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

794|14575|2|11|196||102||BILL NO 11|H1|0.0|||||15/11/2024 02:49:30|

795|14576|2|11|196||102||GLAZING |H1|0.0|||||20/07/2023 02:08:24|

796|33655|2|11|196||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:27:00|

797|14577|2|11|196||102||MIRRORS |H3|0.0|||||20/07/2023 02:08:24|

798|33447|2|11|196||165||6.5mm Thick silver float glass mirror lead backed with polished and rounded edges, holed for and fixed with chromium plated dome capped mirror screws and fixed into fischer wall plugs in brickwork/blockwork or concrete|H2|0.0|||||14/11/2024 05:45:26|

799|33448|2|11|196| A|165.H||Mirror, size 600 x 1 000mm high |No|2|||||14/11/2024 06:02:05|

800|33576|2|11|196| B|165.H||Mirror, size 2 000 x 1 300mm high |No|1|||||14/11/2024 11:16:58|

801|33609|2|11|196| C|165.H||Mirror, size 600 x 1 400mm high |No|1|||||15/11/2024 12:01:51|

802|33610|2|11|196| D|165.H||Mirror, size 2 080 x 1 400mm high |No|1|||||15/11/2024 12:02:01|

803|33611|2|11|196| E|165.H||Mirror, size 2 630 x 1 400mm high |No|1|||||15/11/2024 12:02:09|

804|33449|2|11|196||102||SHADING FILM TO EXISTING WINDOWS|H3|0.0|||||14/11/2024 05:54:27|

805|33450|2|11|196||165||Retrofit "Klingshield" or equivalent and approved solar film shading tint vinyl with a minimum of 50% tint to the inside of the existing glazing of shopfronts and windows  including cleaning of surfaces prior to application and all necessary adhesives, complete as per manufacturers instructions and specifications to|H2|0.0|||||14/11/2024 06:01:15|

806|33451|2|11|196| F|165.H||Glazing of existing windows and shopfronts, complete|m2|251|||||14/11/2024 06:00:02|

807|0|2|11|||||||0.0|||||11/06/2025 12:00:00|

808|14542|2|12|197||||SECTION 2|H1|0.0|||||20/07/2023 02:08:24|

809|14543|2|12|197||66||BILL NO 12|H1|0.0|||||15/11/2024 02:49:35|

810|14544|2|12|197||66||PAINTWORK|H1|0.0|||||20/07/2023 02:08:24|

811|33656|2|12|197||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:27:05|

812|21018|2|12|197||||SUPPLEMENTARY PREAMBLES|H3|0.0|||||20/07/2023 02:08:24|

813|21019|2|12|197||66||Previously painted plastered surfaces|H2|0.0|||||20/07/2023 02:08:24|

814|21020|2|12|197||66||Surfaces shall be thoroughly washed down and allowed to dry completely before any paint is applied. Blistered or peeling paint shall be completely removed and cracks shall be opened, filled with a suitable filler and finished smooth||0.0|||||20/07/2023 02:08:24|

815|21021|2|12|197||66||Previously painted metal surfaces|H2|0.0|||||20/07/2023 02:08:24|

816|21022|2|12|197||66||Surfaces shall be thoroughly rubbed and cleaned down. Blistered or peeling paint shall be completely removed down to bare metal||0.0|||||20/07/2023 02:08:24|

817|21023|2|12|197||66||Previously painted wood surfaces|H2|0.0|||||20/07/2023 02:08:24|

818|21024|2|12|197||66||Surfaces shall be thoroughly cleaned down. Blistered or peeling paint shall be completely removed and cracks and crevices shall be primed, filled with suitable filler and finished smooth||0.0|||||20/07/2023 02:08:24|

819|14545|2|12|197||||COLOURS|H3|0.0|||||20/07/2023 02:08:24|

820|14546|2|12|197||||Unless otherwise described paintwork on ceilings shall be deemed to be in the "White" colour group and paintwork on all other components shall be deemed to be in the "Pastel" colour group in accordance with the Natural Colour System (NCS) adopted by the SA National Standards||0.0|||||20/07/2023 02:08:24|

821|26411|2|12|198||||ON INTERNAL FLOATED PLASTER SURFACES|H3|0.0|||||20/07/2023 02:08:24|

822|33523|2|12|198||||Prepare, make good defective plaster and apply one coat Plascon or equivalent and approved plaster primer, one coat Plascon or equivalent and approved universal undercoat and two coats Plascon or equivalent and approved "wall and all" washable acrylic matt paint (Code: WAA1), in accordance to the manufacturer's specifications, to approved colour to|H2|0.0|||||15/11/2024 02:59:28|

823|33524|2|12|198| A|||Walls ("White" colour group)|m2|5|||||14/11/2024 07:45:55|

824|26413|2|12|198||||Prepare, skim existing surface and apply one coat Plascon or equivalent and approved plaster primer, one coat Plascon or equivalent and approved universal undercoat and two coats Plascon or equivalent and approved "wall and all" washable acrylic matt paint (Code: WAA1), in accordance to the manufacturer's specifications, to approved colour to|H2|0.0|||||15/11/2024 02:59:40|

825|24151|2|12|198| B|||Walls ("White" colour group)|m2|427|||||14/11/2024 07:43:40|

826|33521|2|12|198||||ON CONCRETE SURFACES|H3|0.0|||||14/11/2024 07:45:05|

827|33522|2|12|198||||Prepare, skim existing surface and apply one coat Plascon or equivalent and approved plaster primer, one coat Plascon or equivalent and approved universal undercoat and two coats Plascon or equivalent and approved "wall and all" washable acrylic matt paint (Code: WAA1), in accordance to the manufacturer's specifications, to approved colour to|H2|0.0|||||14/11/2024 08:00:05|

828|33566|2|12|198| C|||Isolated and projecting columns ("White" colour group)|m2|33|||||14/11/2024 10:24:06|

829|33565|2|12|198| D|||Soffits and sides beams ("White" colour group)|m2|20|||||14/11/2024 10:24:02|

830|14556|2|12|198||166||ON SKIM PLASTER, ETC.|H3|0.0|||||20/07/2023 02:08:24|

831|33519|2|12|198||166||Prepare, make good defective plaster and apply one coat Plascon or equivalent and approved gypsum plaster primer, one coat Plascon or equivalent and approved universal undercoat and two coats Plascon or equivalent and approved "wall and all" washable acrylic matt paint (Code: WAA1), in accordance to the manufacturer's specifications, to approved colour to|H2|0.0|||||15/11/2024 02:59:47|

832|33520|2|12|198| E|||Drywalls partitions (''White" colour group)|m2|78|||||14/11/2024 07:47:47|

833|33525|2|12|199||166||Prepare, make good defective plaster and apply one coat Plascon or equivalent and approved gypsum plaster primer, one coat Plascon or equivalent and approved universal undercoat and two coats Plascon or equivalent and approved washable acrylic matt "ceiling" paint (Code: GR-N03), in accordance to the manufacturer's specifications, to approved colour to|H2|0.0|||||15/11/2024 02:59:53|

834|33526|2|12|199| A|||Internal soffits of suspended ceilings and bulkheads ("Deep" colour group)|m2|43|||||14/11/2024 07:55:59|

835|33577|2|12|199| B|||Internal vertical sides of bulkheads ("Deep" colour group)|m2|1|||||14/11/2024 11:18:32|

836|32365|2|12|199||166||Prepare, make good defective plaster and apply one coat Plascon or equivalent and approved gypsum plaster primer, one coat Plascon or equivalent and approved universal undercoat and two coats Plascon or equivalent and approved washable acrylic matt "ceiling" paint (Code: WAA1), in accordance to the manufacturer's specifications, to approved colour to|H2|0.0|||||15/11/2024 02:59:59|

837|28547|2|12|199| C|||Internal soffits of suspended ceilings and bulkheads ("White" colour group)|m2|181|||||17/07/2024 01:23:08|

838|21029|2|12|199| D|||Internal vertical sides of bulkheads ("White" colour group)|m2|20|||||14/11/2024 07:52:15|

839|14567|2|12|199||168||ON WOOD, ETC |H3|0.0|||||20/07/2023 02:08:24|

840|33527|2|12|199||166||Prepare, make good defective plaster and apply one coat Plascon or equivalent and approved wood primer, one coat Plascon or equivalent and approved universal undercoat and two coats Plascon or equivalent and approved washable acrylic matt "ceiling" paint (Code: WAA1), in accordance to the manufacturer's specifications, to approved colour to|H2|0.0|||||18/11/2024 05:44:02|

841|33528|2|12|199| E|||Timber slats only on timber slatted ceilings ("White" colour group)|m2|85|||||14/11/2024 07:56:56|

842|25596|2|12|200||116||Prepare and prime one coat Plascon or equivalent and approved wood primer, one coat one coat Plascon or equivalent and approved universal undercoat and two coats Plascon or equivalent and approved washable acrylic matt "wood" paint (Code: GR-N03), in accordance to the manufacturer's specifications, to approved colour to|H2|0.0|||||14/11/2024 08:00:43|

843|23723|2|12|200| A|168.D||General surfaces of doors |m2|35|||||20/07/2023 02:08:24|

844|33529|2|12|200| B|168.D||General surfaces of doors frames|m2|14|||||14/11/2024 07:58:43|

845|0|2|12|||||||0.0|||||11/06/2025 12:00:00|

846|33271|2|13|202||166||SECTION 2|H1|0.0|||||12/11/2024 10:36:21|

847|33272|2|13|202||166||BILL NO 13|H1|0.0|||||15/11/2024 02:49:40|

848|33273|2|13|202||166||PAPERHANGING|H1|0.0|||||12/11/2024 10:36:22|

849|33657|2|13|202||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:27:10|

850|33274|2|13|202||153||SUPPLEMENTARY PREAMBLES |H3|0.0|||||12/11/2024 10:36:22|

851|33275|2|13|202||||Preparatory work to previously painted surfaces|H2|0.0|||||12/11/2024 10:36:22|

852|33276|2|13|202||||Surfaces shall be thoroughly washed down and allowed to dry completely before paperhanging is commenced. Blistered and peeling paint shall be completely removed and cracks shall be opened, filled with a suitable filler and finished smooth. All surfaces shall be painted with a single coat of interior quality PVA emulsion paint||0.0|||||12/11/2024 10:36:22|

853|33277|2|13|202||||PAPERHANGING TO EXISTING WORK|H3|0.0|||||12/11/2024 10:36:22|

854|33278|2|13|202||||Gloss vinyl wallpaper (PC Amount: R800/m2) on previously painted surfaces, including adhesives and one coat preparatory emulsion paint as per manufacturers specification to|H2|0.0|||||14/11/2024 08:08:39|

855|33280|2|13|202| A|||Walls and columns including narrow widths|m2|63|||||12/11/2024 10:36:22|

856|0|2|13|||||||0.0|||||11/06/2025 12:00:00|

857|19530|2|14|203||178||SECTION 2 |H1|0.0|||||20/07/2023 02:08:24|

858|19531|2|14|203||178||BILL NO 14|H1|0.0|||||15/11/2024 02:49:44|

859|19532|2|14|203||178||BUILDERSWORK IN CONNECTION WITH ELECTRICAL INSTALLATION (PROVISIONAL)|H1|0.0|||||20/07/2023 02:08:24|

860|33658|2|14|203||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:27:15|

861|32441|2|14|203||181||OPENINGS THROUGH WALLS, ETC |H3|0.0|||||17/07/2024 04:50:11|

862|20897|2|14|203||||Cutting through floors, walls and ceilings|H2|0.0|||||20/07/2023 02:08:24|

863|32430|2|14|203| A|||Cutting floor chasings 30mm wide into surface beds|m|100|||||17/07/2024 05:16:29|

864|20899|2|14|203| B|||Cutting vertical chasings 30mm wide into brickwork/blockwork|m|150|||||20/07/2023 02:08:24|

865|20900|2|14|203| C|||Ditto, but 40mm wide|m|75|||||20/07/2023 02:08:24|

866|20901|2|14|203||||Making good internal cement plaster|H2|0.0|||||20/07/2023 02:08:24|

867|20902|2|14|203| D|||30mm Wide vertical chasings in brick walls|m|150|||||20/07/2023 02:08:24|

868|20903|2|14|203| E|||Ditto, but 40mm wide|m|75|||||20/07/2023 02:08:24|

869|32431|2|14|203||||Making good concrete surface beds and screeds|H2|0.0|||||17/07/2024 04:42:14|

870|32432|2|14|203| F|||Floor surfaces where 30mm wide chasings were cut|m2|10|||||17/07/2024 04:42:15|

871|20906|2|14|203||181||Breaking out and forming opening for cable installation through brick walls including necessary precast concrete lintels, close up opening around duct and making good all trades |H2|0.0|||||20/07/2023 02:08:24|

872|20907|2|14|203| G|181.C||Opening 200 x 300mm through 220mm thick brick wall |No|10|||||20/07/2023 02:08:24|

873|32433|2|14|204||||SLEEVES, ETC|H3|0.0|||||17/07/2024 04:42:21|

874|32434|2|14|204||178||Pipes |H2|0.0|||||17/07/2024 04:42:21|

875|32435|2|14|204| A|178.B||25mm Diameter PVC sleeve with draw wire laid in ground under solid floors not exceeding 1m deep |m|100|||||17/07/2024 04:42:22|

876|32437|2|14|204||178||Fittings |H2|0.0|||||17/07/2024 04:42:22|

877|32438|2|14|204| B|178.F||Extra over for 25mm bend|No|35|||||17/07/2024 04:42:22|

878|0|2|14|||||||0.0|||||11/06/2025 12:00:00|

879|19557|2|15|206||181||SECTION 2 |H1|0.0|||||20/07/2023 02:08:24|

880|19558|2|15|206||181||BILL NO 15|H1|0.0|||||15/11/2024 02:49:48|

881|19559|2|15|206||181||BUILDERSWORK IN CONNECTION WITH MECHANICAL INSTALLATION (PROVISIONAL)|H1|0.0|||||20/07/2023 02:08:24|

882|33659|2|15|206||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:27:20|

883|20919|2|15|206||181||OPENINGS THROUGH WALLS, ETC |H3|0.0|||||20/07/2023 02:08:24|

884|20920|2|15|206||181||Breaking out and forming opening for air conditioning ducts through 220mm brickwalls including necessary precast concrete lintols, close up opening around duct and making good all trades|H2|0.0|||||20/07/2023 02:08:24|

885|20921|2|15|206| A|181.C||Opening 200 x 200mm through 220mm thick brickwall|No|9|||||17/07/2024 05:58:09|

886|20922|2|15|206| B|||Opening 300 x 300mm, ditto|No|5|||||20/07/2023 02:08:24|

887|20923|2|15|206| C|||Opening 600 x 600mm, ditto|No|3|||||15/11/2024 03:05:29|

888|23338|2|15|206||181||Breaking out and forming opening for air conditioning ducts through 280mm brickwalls including necessary precast concrete lintols, close up opening around duct and making good all trades|H2|0.0|||||20/07/2023 02:08:24|

889|23319|2|15|206| D|181.C||Opening 800 x 800mm through 280mm thick cavity brickwall|No|5|||||15/11/2024 03:05:18|

890|20939|2|15|206||||Access hatches in drywall bulkheads|H2|0.0|||||20/07/2023 02:08:24|

891|20940|2|15|206| E|||600 x 600mm openings|No|10|||||20/07/2023 02:08:24|

892|0|2|15|||||||0.0|||||11/06/2025 12:00:00|

893|32975|2|16|207||139||SECTION NO. 2|H1|0.0|||||11/11/2024 08:48:43|

894|32976|2|16|207||139||BILL NO. 16|H1|0.0|||||15/11/2024 03:06:11|

895|32977|2|16|207||139||PROVISIONAL SUMS|H1|0.0|||||11/11/2024 08:48:43|

896|33660|2|16|207||22||NOTE  Tenderers are advised to study the General Preambles for Trade 2017 before pricing this Bill.  -------------||0.0|||||18/11/2024 04:27:26|

897|32978|2|16|207||139||SUPPLEMENTARY PREAMBLES|H2|0.0|||||11/11/2024 08:48:43|

898|32979|2|16|207||||All prime cost items and provisional sums are "NET" i.e. no Builder's discount is allowed.||0.0|||||11/11/2024 08:48:43|

899|32980|2|16|207||||All amounts stated for prime cost items are for goods delivered to the site. The Contractor shall allow opposite the relevant items for taking delivery, unloading, checking against invoices and/or delivery notes, getting in, unpacking, storing, hoisting and fixing of such goods||0.0|||||11/11/2024 08:48:43|

900|32981|2|16|207||||The Contractor shall check carefully the quantity and condition of all goods on taking delivery as any goods subsequently found to be missing or damaged shall be replaced at the Contractor's expense.||0.0|||||11/11/2024 08:48:43|

901|32982|2|16|208||||Without in any way limiting the meaning and interpretation, general attendance on subcontractors shall include free of charge to the subcontractor the following services for the purpose of the relative subcontract works: 1.access to the site and to the places where the work is to be carried out, including the use of any temporary personnel hoists erected by the Contractor for his own use; 2.the provision of water, lighting and electric power to a position within 50 metres of the place where the work is to be carried out; 3.the use of erected scaffolding belonging to the Contractor, in common with others having the like right whilst it so remains erected upon the site; 4.the use of site services, messrooms, toilets, health and welfare facilities and the like, where provided;  In the event of the Contractor allowing for profit and/or attendance, the amount(s) will be subject to adjustment pro-rata to the actual value of the subcontractor work calculated in direct ratio to any adjustment to the Provisional Sum.||0.0|||||18/11/2024 05:45:32|

902|32983|2|16|208||||The cost of fuel for the commissioning of plant shall be borne by the selected subcontractor appointed for the relevant subcontractor works in terms of the conditions under which they have/are to contract for the specialist work involved.||0.0|||||11/11/2024 08:48:43|

903|32988|2|16|208||||PROVISIONAL SUMS FOR SPECIALIST SUB-CONTRACT WORKS|H2|0.0|||||18/11/2024 05:46:10|

904|32989|2|16|208||140||ELECTRICAL INSTALLATION|H3|0.0|||||11/11/2024 08:48:43|

905|32990|2|16|208||140||Allow the Provisional Tendered Sum of as per Section 3 of this document nett for the electrical installations to be executed by the domestic sub-contractor ||0.0|||||12/11/2024 04:12:22|

906|32991|2|16|208| A|140.1||Add for profit |Item|1.00|||||11/11/2024 08:48:43|

907|32992|2|16|208| B|140.2||Allow for general attendance on above |Item|1.00|||||11/11/2024 08:48:44|

908|33005|2|16|208||140||FIRE PROTECTION INSTALLATION|H3|0.0|||||11/11/2024 08:48:44|

909|33006|2|16|208||140||Allow the Provisional Tendered Sum of as per Section 4 of this document nett for the fire protection installations to be executed by the domestic sub-contractor||0.0|||||12/11/2024 04:12:31|

910|33007|2|16|209| A|140.5||Add for profit |Item|1.00|||||11/11/2024 08:48:44|

911|33008|2|16|209| B|140.6||Allow for general attendance on above |Item|1.00|||||11/11/2024 08:48:44|

912|33009|2|16|209||140||MECHANICAL INSTALLATION|H3|0.0|||||11/11/2024 08:48:44|

913|33010|2|16|209||140||Allow the Provisional Tendered Sum of as per Section 5 of this document nett for mechanical installations to be executed by the domestic sub-contractor ||0.0|||||12/11/2024 04:12:42|

914|33011|2|16|209| C|140.3||Add for profit |Item|1.00|||||11/11/2024 08:48:44|

915|33012|2|16|209| D|140.4||Allow for general attendance on above |Item|1.00|||||11/11/2024 08:48:44|

916|33013|2|16|209||140||WET SERVICES INSTALLATION|H3|0.0|||||12/11/2024 04:09:06|

917|33014|2|16|209||140||Allow the Provisional Tendered Sum of as per Section 6 of this document nett for the wet services installations to be executed by the domestic sub-contractor||0.0|||||12/11/2024 04:13:26|

918|33015|2|16|209| E|141.7||Add for profit |Item|1.00|||||11/11/2024 08:48:44|

919|33016|2|16|209| F|141.8||Allow for general attendance on above |Item|1.00|||||11/11/2024 08:48:45|

920|33312|2|16|209||141||ADDITIONAL ATTENDANCES |H3|0.0|||||12/11/2024 04:13:55|

921|33313|2|16|209||141||NOTE:  The following works are NOT included in this Contract and the Contractor will receive no cash or other discounts of the costs thereof. ||0.0|||||12/11/2024 04:13:55|

922|33314|2|16|209||141||Allow for giving access to the works, general attendance on and all reasonable assistance to specialists employed direct by the Employer (or his contractor or tenants) for the execution of the following works.               ------------- ||0.0|||||12/11/2024 04:13:55|

923|33315|2|16|209| G|141.9||Specialists installing the data and Wi-Fi system, including equipment, cabling, etc to the Nelson Mandela Gateway Building|Item|1.00|||||12/11/2024 04:14:34|

924|33316|2|16|209| H|141.10||Specialists installing the alarm system, including equipment, cabling, etc to the Nelson Mandela Gateway Building|Item|1.00|||||12/11/2024 04:14:43|

925|33317|2|16|209| J|141.11||Specialists installing the CCTV system including equipment, cabling, etc to the Nelson Mandela Gateway Building|Item|1.00|||||12/11/2024 04:14:52|

926|33031|2|16|210||141||BUDGETARY ALLOWANCES|H2|0.0|||||11/11/2024 08:48:45|

927|33032|2|16|210||197||Amounts allowed under this heading will be for work to be executed by the Contractor and/or sub-contractor and is to be remeasured after completion with rates from the Bills of Quantities used for measurement purposes and will be used at the discretion of the Architect and deducted in whole or in part if not required.  -------------||0.0|||||11/11/2024 08:48:45|

928|33308|2|16|210||26||Removal of existing joinery|H3|0.0|||||12/11/2024 03:53:15|

929|33309|2|16|210| A|26.G||Provide the sum of R50 000.00 (Fifty Thousand Rand) for the removal of existing joinery, etc|Item|1.00|50 000.00|50 000.00|||12/11/2024 03:53:45|

930|33310|2|16|210||26||General Demolitions|H3|0.0|||||12/11/2024 03:54:22|

931|33311|2|16|210| B|26.G||Provide the sum of R15 000.00 (Fifteen Thousand Rand) for general demolitions, etc|Item|1.00|15 000.00|15 000.00|||12/11/2024 03:52:26|

932|0|2|16|||||||0.0|||||11/06/2025 12:00:00|

933|16691|2|17|212|1|||ALTERATIONS|Page|146|0||||20/04/2022 09:55:45|

934|15132|2|17|212|2|||WATERPROOFING|Page|149|0||||20/04/2022 09:55:45|

935|15105|2|17|212|3|||CARPENTRY AND JOINERY|Page|155|0||||20/04/2022 09:55:45|

936|15060|2|17|212|4|||CEILINGS, PARTITIONS, ACCESS FLOORING|Page|165|0||||20/04/2022 09:55:45|

937|15467|2|17|212|5|||FLOOR COVERING, WALL LINING, ETC|Page|168|0||||20/04/2022 09:55:45|

938|14988|2|17|212|6|||IRONMONGERY|Page|174|0||||20/04/2022 09:55:45|

939|14847|2|17|212|7|||METALWORK|Page|181|0||||20/04/2022 09:55:45|

940|14821|2|17|212|8|||PLASTERING|Page|184|0||||20/04/2022 09:55:45|

941|14769|2|17|212|9|||TILING|Page|190|0||||20/04/2022 09:55:45|

942|14581|2|17|212|10|||PLUMBING AND DRAINAGE|Page|195|0||||20/04/2022 09:55:45|

943|14573|2|17|212|11|||GLAZING|Page|196|0||||20/04/2022 09:55:45|

944|14541|2|17|212|12|||PAINTWORK|Page|201|0||||20/04/2022 09:55:45|

945|33270|2|17|212|13|||PAPERHANGING|Page|202|0||||12/11/2024 10:36:21|

946|19529|2|17|212|14|||BUILDERSWORK ICW ELECTRICAL INSTALLATION|Page|205|0||||20/04/2022 09:55:45|

947|19556|2|17|212|15|||BUILDERSWORK ICW MECHANICAL INSTALLATION|Page|206|0||||20/04/2022 09:55:45|

948|32974|2|17|212|16|||PROVISIONAL SUMS|Page|211|0||||11/11/2024 08:48:43|

949|33054|3|1|213||||SECTION NO. 3|H1|0.0|||||11/11/2024 10:14:41|

950|33053|3|1|213||||BILL NO. 1|H1|0.0|||||11/11/2024 10:14:56|

951|33055|3|1|213||||LV RETICULATION|H1|0.0|||||18/11/2024 05:47:11|

952|33056|3|1|213||||The Supply, delivery and installation of SABS approved material, accessories and equipment as specified. ||0.0|||||18/11/2024 05:48:29|

953|33057|3|1|213||||ARMOURED CABLES|H2|0.0|||||11/11/2024 10:15:35|

954|33058|3|1|213||||Supply and Install 600/1000V grade PVC/SWA/PVC insulated stranded copper conductors drawn into conduit, laid in ground, sleeves or cable tray.|H3|0.0|||||11/11/2024 10:15:35|

955|33059|3|1|213| A|||16mm² 4 core PVC / SWA / PVC |m|180|||||11/11/2024 10:15:36|

956|33060|3|1|213| B|||6mm² 4 core 1000V  PVC / SWA / PVC Copper Cable|m|60|||||11/11/2024 10:15:36|

957|33061|3|1|213||||BARE COPPER EARTH WIRE|H2|0.0|||||11/11/2024 10:15:37|

958|33062|3|1|213| C|||10mm²  Bare Copper Earth Wire|m|180|||||11/11/2024 10:15:37|

959|33063|3|1|213| D|||4mm²  Bare Copper Earth Wire|m|75|||||11/11/2024 10:15:37|

960|33064|3|1|213||||CABLE TERMINATIONS(PVC/SWA/PVC)|H2|0.0|||||18/11/2024 05:47:42|

961|33065|3|1|213||||Supply and Install cable terminations complete including lugs, glands, shrouds, ferrules|H3|0.0|||||11/11/2024 10:15:37|

962|33066|3|1|213| E|||16mm² 4 core 1000V  PVC / SWA / PVC Copper Cable|m|24|||||11/11/2024 10:15:37|

963|33067|3|1|213| F|||6mm² 4 core 1000V  PVC / SWA / PVC Copper Cable|m|24|||||11/11/2024 10:15:37|

964|33068|3|1|213||||CABLE TERMINATIONS- BARE COPPER EARTH WIRE|H2|0.0|||||11/11/2024 10:15:38|

965|33069|3|1|213||||Supply and Install cable terminations complete including lugs, glands, shrouds, ferrules|H3|0.0|||||11/11/2024 10:15:38|

966|33070|3|1|213| G|||10mm²  Bare Copper Earth Wire|EA|24|||||11/11/2024 10:15:38|

967|33071|3|1|213| H|||4mm²  Bare Copper Earth Wire|EA|24|||||11/11/2024 10:15:38|

968|33072|3|1|214||||LV DISTRIBUTION BOARDS |H2|0.0|||||11/11/2024 10:15:38|

969|33073|3|1|214| A|||Upgrade the Main Distribution Board|EA|1|||||11/11/2024 10:15:38|

970|33074|3|1|214| B|||Upgrade DB-Q1 to a 42 way|EA|1|||||11/11/2024 10:15:38|

971|33075|3|1|214| C|||Upgrade DB-Q2 to a 42 way|EA|2|||||11/11/2024 10:15:39|

972|0|3|1|||||||0.0|||||11/06/2025 12:00:00|

973|33076|3|2|216||||SECTION NO. 3|H1|0.0|||||11/11/2024 10:16:55|

974|33077|3|2|216||||BILL NO. 2|H1|0.0|||||11/11/2024 10:17:05|

975|33078|3|2|216||||SMALL POWER AND LIGHTING INSTALLATIONS|H1|0.0|||||18/11/2024 05:48:08|

976|33079|3|2|216||||The Supply, delivery and installation of SABS approved material, accessories and equipment as specified. ||0.0|||||18/11/2024 05:48:38|

977|33080|3|2|216||||Chiselling Work|H3|0.0|||||11/11/2024 10:20:17|

978|33081|3|2|216| A|||Provisional sum for chiselling work required to install the conduits and wall box|SUM|3|||||18/11/2024 05:57:35|

979|33082|3|2|216||||Draw Wires|H3|0.0|||||11/11/2024 10:20:21|

980|33083|3|2|216| B|||Supply and install a 0,6mm diameter galvanised draw wire in conduit for data installation|m|1250|||||11/11/2024 10:18:55|

981|33084|3|2|216||||Galvanised Conduit|H3|0.0|||||11/11/2024 10:20:25|

982|33085|3|2|216| C|||25mm - Galvanised conduit including bending, short lengths, draw boxes, cutting, bands, jointing, couplings, saddles and wastage as per SABS 1065. Fixed to surface or laid in or flush|m|180|||||11/11/2024 10:18:56|

983|33086|3|2|216||||Conduit Work|H3|0.0|||||11/11/2024 10:18:56|

984|33087|3|2|216||||Supply, delivery and installation of SABS approved PVC Conduits completed with all required conduit accessories.   |H3|0.0|||||11/11/2024 10:20:57|

985|33088|3|2|216||||Built or Chase into brick or concrete work:|H4|0.0|||||11/11/2024 10:20:45|

986|33089|3|2|216| D|||20mm PVC Conduit|m|2250|||||11/11/2024 10:18:56|

987|33090|3|2|216| E|||25mm PVC Conduit|m|2350|||||11/11/2024 10:18:57|

988|33091|3|2|216||||In Ceiling space and Timber work:|H4|0.0|||||11/11/2024 10:20:50|

989|33092|3|2|216| F|||20mm PVC Conduit|m|1700|||||11/11/2024 10:18:57|

990|33093|3|2|217| A|||25mm PVC Conduit|m|1920|||||11/11/2024 10:18:57|

991|33094|3|2|217||||Conduit Boxes|H3|0.0|||||11/11/2024 10:18:57|

992|33095|3|2|217||||Supply and installation of SABS approved conduit boxes, installed in the run of the conduit installation, cast into concrete and built into brickwork or flush inside false ceiling spaces, complete with all required conduit termination accessories. |H4|0.0|||||11/11/2024 10:18:57|

993|33096|3|2|217| B|||20mm diameter 4 way type(round box)|EA|30|||||11/11/2024 10:18:57|

994|33097|3|2|217||||Wall Boxes|H3|0.0|||||11/11/2024 10:18:58|

995|33098|3|2|217||||Supply and installation of SABS approved galvanised pressed steel wall boxes for building flush into brickwork or drywall work.|H3|0.0|||||11/11/2024 10:21:12|

996|33099|3|2|217||||Flush mounted type:|H4|0.0|||||11/11/2024 10:18:58|

997|33100|3|2|217| C|||100 x 50 x 50mm|EA|27|||||11/11/2024 10:18:58|

998|33101|3|2|217| D|||100 x 100 x 50mm|EA|27|||||11/11/2024 10:18:58|

999|33102|3|2|217| E|||100 x 50 x 50mm Standard white coverplates complete with chrome screws.|EA|27|||||11/11/2024 10:18:58|

1000|33103|3|2|217| F|||100 x 100 x 50mm Standard white coverplates complete with chrome screws.|EA|27|||||11/11/2024 10:18:58|

1001|33104|3|2|217||||PVC INSULATED GENERAL PURPOSE CONDUCTORS|H2|0.0|||||11/11/2024 10:19:37|

1002|33105|3|2|217||||Conductors drawn into conduit or installed in wiring channel |H3|0.0|||||11/11/2024 10:19:47|

1003|33106|3|2|217| G|||1.5mm² |m|1150|||||11/11/2024 10:18:59|

1004|33107|3|2|217| H|||2.5mm² |m|1650|||||11/11/2024 10:18:59|

1005|33108|3|2|217| J|||4mm² |m|1650|||||11/11/2024 10:18:59|

1006|33109|3|2|217| K|||6mm² |m|1600|||||11/11/2024 10:19:00|

1007|33110|3|2|218||||Supply and installation of stranded bare copper earth wire along with PVC wiring in conduits. Tendered rates shall make provision for wastage.|H3|0.0|||||11/11/2024 10:19:50|

1008|33111|3|2|218| A|||1.5mm² |m|2700|||||11/11/2024 10:19:00|

1009|33112|3|2|218| B|||2.5mm² |m|3300|||||11/11/2024 10:19:00|

1010|33113|3|2|218| C|||4mm² |m|1600|||||11/11/2024 10:19:00|

1011|33114|3|2|218| D|||450 x 450mm Bonding tray in roof space|m|900|||||11/11/2024 10:19:00|

1012|33115|3|2|218||||Light Switches|H3|0.0|||||11/11/2024 10:19:00|

1013|33116|3|2|218||||Supply and installation of SABS approved type 16A flush and surface type light switches. Final paint finishes shall be confirmed at a later stage, allowance shall however be made as specified in the general specification. All boxes for flush mounting meas|H4|0.0|||||11/11/2024 10:19:01|

1014|33117|3|2|218| E|||1 Lever 1 way|EA|18|||||11/11/2024 10:19:01|

1015|33118|3|2|218| F|||1 Lever 2 way|EA|4|||||11/11/2024 10:19:01|

1016|33119|3|2|218| G|||2 Lever 2 way|EA|5|||||11/11/2024 10:19:01|

1017|33120|3|2|218||||Interior: Light Fittings|H3|0.0|||||11/11/2024 10:21:33|

1018|33121|3|2|218||||Suppy, delievery to site, storage and installation of the below specified light fittings complete with lamps,  fixing material, mounting  and tubes. Allowance must be made in the rates for all the required fixing materials and accessories.  |H4|0.0|||||11/11/2024 10:21:37|

1019|33122|3|2|218| H|||Type F12- 53W LED recessed panel fitting,1200mm X 600mm , 5300l , 4000k|EA|109|||||11/11/2024 10:19:02|

1020|33123|3|2|218| J|||Type A- 40W, 240V T8 White,  Tri-proof light batten tub ,explosion proof LED tube 120mm, 2800lm 4FT|EA|0.0||||Rate Only|11/11/2024 10:22:25|

1021|33124|3|2|218| K|||Type V- 40W, 240V T8 White,  Vapour Proof ,Tri-proof light batten tub ,explosion proof LED tube 1200mm, 2800lm 4FT|EA|0.0||||Rate Only|11/11/2024 10:22:35|

1022|33125|3|2|218| L|||Type OC: Ceiling and surface mount , round LED downligters com[lete with accessories|EA|33|||||11/11/2024 10:19:02|

1023|33126|3|2|219| A|||MS: Ceiling and surface mount , motion sensors to be installed in bathrooms complete with accessories|EA|2|||||11/11/2024 10:19:02|

1024|33127|3|2|219||||Socket Outlets|H3|0.0|||||11/11/2024 10:21:51|

1025|33128|3|2|219||||Supply and installation of SABS approved switched and unswitched type flush and surface mounted type 16A switched socket outlets suitable for mounting in flush steel wall boxes or in steel pedestal units or on surface.|H3|0.0|||||11/11/2024 10:19:03|

1026|33129|3|2|219||||The final colour of the paint finish shall be confirmed at a later stage, allowance shall be made as specified in the specification.||0.0|||||11/11/2024 10:19:03|

1027|33130|3|2|219||||Flush switched sockets type wall surfaces:|H4|0.0|||||11/11/2024 10:21:56|

1028|33131|3|2|219| B|||16A SA/Euro Combined switch socket outlets  + US|EA|5|||||11/11/2024 10:19:03|

1029|33132|3|2|219| C|||16A SA/Euro normal double switch socket outlets|EA|26|||||11/11/2024 10:19:03|

1030|33133|3|2|219| D|||20A, DP Isolator(HVAC)|EA|19|||||11/11/2024 10:19:03|

1031|33134|3|2|219||||Flush switched sockets type in power skirting:|H4|0.0|||||11/11/2024 10:22:00|

1032|33135|3|2|219| E|||16A SA/Euro normal double switch socket outlets|EA|79|||||11/11/2024 10:19:04|

1033|33136|3|2|219||||Power Trunking/ Skirting|H3|0.0|||||11/11/2024 10:19:04|

1034|33137|3|2|219| F|||2 compartment power skirting installed in the offices on floor and under service desk and reception desk (To include All elbows, corners sections, T-sections& end caps)|m|820|||||11/11/2024 10:19:04|

1035|33138|3|2|219| G|||127 mm wide x 76 mm deep (for electronic services, as Cabstrut P9000)|m|170|||||11/11/2024 10:19:04|

1036|33139|3|2|219| H|||RJ45 point|EA|99|||||11/11/2024 10:19:04|

1037|33140|3|2|219| J|||RJ15 point|EA|3|||||11/11/2024 10:19:04|

1038|33141|3|2|219||||Electrical Tests|H3|0.0|||||11/11/2024 10:19:04|

1039|33142|3|2|219| K|||Manuals, Documentation, As Builts|SUM|3|||||11/11/2024 10:19:05|

1040|33143|3|2|219| L|||12 Month Maintenance Guarantee|SUM|3|||||11/11/2024 10:19:05|

1041|33144|3|2|220| A|||Training of Personnel|SUM|3|||||11/11/2024 10:19:05|

1042|33145|3|2|220| B|||Making provision for the required inspection, tests and the commissioning of the complete installation and the issuing of the required certificate of compliance (CoC)|SUM|3|||||11/11/2024 10:19:05|

1043|0|3|2|||||||0.0|||||11/06/2025 12:00:00|

1044|33146|3|3|222||||SECTION NO. 3|H1|0.0|||||11/11/2024 10:23:24|

1045|33147|3|3|222||||BILL NO. 3|H1|0.0|||||11/11/2024 10:23:35|

1046|33148|3|3|222||||ACCESS CONTROL SYSTEM|H1|0.0|||||11/11/2024 10:28:14|

1047|33166|3|3|222||||(To be done by a specialist contractor with experience)||0.0|||||11/11/2024 10:28:08|

1048|33149|3|3|222||||The Supply, delivery and installation of SABS approved material, accessories and equipment as specified. |H2|0.0|||||18/11/2024 05:50:00|

1049|33150|3|3|222| A|||IP Intelligent Biometric Finger PrintReader only- Entry|EA|8|||||11/11/2024 10:23:58|

1050|33151|3|3|222| B|||No Touch Exit on door safe side|EA|8|||||11/11/2024 10:23:58|

1051|33152|3|3|222| C|||Magnetic Door Lock 300kg|EA|8|||||11/11/2024 10:23:58|

1052|33153|3|3|222| D|||Dorma Door Closer|EA|8|||||11/11/2024 10:23:58|

1053|33154|3|3|222| E|||Door Monitor|EA|8|||||11/11/2024 10:23:59|

1054|33155|3|3|222| F|||Operators Workstation, 1 x Xeon E5-1620V4 / 3.5 GHz - RAM 16 GB, HDD 500GB,AMD Firepro 2GB Graphics with 4 (Display ports) Outputs, Serial port adaptor, Win10 Pro 64-bit (includes Win 10 Pro 64-bit Licence) - vPro -|EA|3|||||11/11/2024 10:23:59|

1055|33156|3|3|222| G|||Specialized Intergrated Security Software to operate IP access control system, once off license|EA|3|||||11/11/2024 10:23:59|

1056|33157|3|3|222| H|||Relocation of CCTV system|SUM|3|||||11/11/2024 10:23:59|

1057|33158|3|3|222| J|||CAT 6a Cable-yellow|m|1600|||||11/11/2024 10:23:59|

1058|33159|3|3|222| K|||6 -core Mylar cable|m|1600|||||11/11/2024 10:24:00|

1059|33160|3|3|222| L|||2.5mm² 3-core pvc cable|m|1500|||||11/11/2024 10:24:00|

1060|33161|3|3|222| M|||25mm dia PVC conduits including all accessories|m|1450|||||11/11/2024 10:24:00|

1061|33162|3|3|222| N|||Manuals, Documentation, As Builts|SUM|3|||||11/11/2024 10:24:00|

1062|33163|3|3|222| P|||12 Month Maintenance Guarantee|SUM|3|||||11/11/2024 10:24:00|

1063|33164|3|3|223| A|||Training of Personnel|SUM|3|||||11/11/2024 10:24:01|

1064|33165|3|3|223| B|||Testing and Commissioning of Installation|SUM|3|||||11/11/2024 10:24:01|

1065|0|3|3|||||||0.0|||||11/06/2025 12:00:00|

1066|33167|3|4|225||||SECTION NO. 3|H1|0.0|||||11/11/2024 10:28:57|

1067|33168|3|4|225||||BILL NO. 4|H1|0.0|||||11/11/2024 10:29:07|

1068|33169|3|4|225||||FIRE DETECTION AND PROTECTION|H1|0.0|||||11/11/2024 10:29:51|

1069|33170|3|4|225||||The Supply, delivery and installation of SABS approved material, accessories and equipment as specified.   ||0.0|||||18/11/2024 05:51:04|

1070|33171|3|4|225||||Fire Detection relocation , wiring and distribution|H2|0.0|||||11/11/2024 10:30:07|

1071|33172|3|4|225| A|||Relocation of existing addressable Smoke sensing fire detector complete with surface base including required pumbing work|EA|11|||||11/11/2024 10:29:24|

1072|33173|3|4|225| B|||New addressable Smoke sensing fire detector complete with surface base. |EA|11|||||11/11/2024 10:29:24|

1073|33174|3|4|225| C|||Addressable Heat Sensing fire detector complete with surface base. |EA|3|||||11/11/2024 10:29:24|

1074|33175|3|4|225| D|||Relocation of existing addressable Break Glass Call points complete (Resettable), with surface base including required wiring work|EA|6|||||11/11/2024 10:29:25|

1075|33176|3|4|225| E|||New addressable Break Glass Call points complete (Resettable), with surface base.|EA|6|||||11/11/2024 10:29:25|

1076|33177|3|4|225| F|||Provision of fire escape doors and complete interface with access control system for release of Fire Escape Doors|EA|6|||||11/11/2024 10:29:25|

1077|33178|3|4|225| G|||Relocation  of existing addressable Wall mounted audible alarm (Sounder) complete with surface base.|EA|3|||||11/11/2024 10:29:25|

1078|33179|3|4|225| H|||New addressable Wall mounted audible alarm (Sounder) complete with surface base.|EA|6|||||11/11/2024 10:29:25|

1079|33180|3|4|225| J|||Relocation of addressable Ceiling  mounted Strobe Light complete with surface base.|EA|3|||||11/11/2024 10:29:25|

1080|33181|3|4|225| K|||New addressable Ceiling  mounted Strobe Light complete with surface base.|EA|3|||||11/11/2024 10:29:25|

1081|33182|3|4|226| A|||Addresable Line Isolators with complete accessories. |EA|3|||||11/11/2024 10:29:26|

1082|33183|3|4|226| B|||Fire Retardant (Red) cabling (PH120)|m|1200|||||11/11/2024 10:29:26|

1083|33184|3|4|226| C|||25mm Galvanised Conduit In Ceiling Including all fittings, elbows,tees ,reducers etc|m|150|||||11/11/2024 10:29:26|

1084|33185|3|4|226| D|||Manuals, Documentation, As Builts|Sets|3.0|||||11/11/2024 10:29:26|

1085|33186|3|4|226| E|||12 Month Maintenance Guarantee|SUM|3|||||11/11/2024 10:29:27|

1086|33187|3|4|226| F|||Training of Personnel|SUM|3|||||11/11/2024 10:29:27|

1087|33188|3|4|226| G|||Testing and Commissioning of Installation|SUM|3|||||11/11/2024 10:29:27|

1088|33189|3|4|226| H|||Issuing of Fire Compliance COC by a registered personal|EA|3|||||11/11/2024 10:29:27|

1089|0|3|4|||||||0.0|||||11/06/2025 12:00:00|

1090|33042|3|5|228|1|||LV RETICULATION|Page|215|0||||11/11/2024 08:51:06|

1091|33043|3|5|228|2|||SMALL POWER AND LIGHTING|Page|221|0||||11/11/2024 08:51:19|

1092|33044|3|5|228|3|||ACCESS CONTROL|Page|224|0||||11/11/2024 08:51:25|

1093|33045|3|5|228|4|||FIRE DETECTION|Page|227|0||||11/11/2024 08:51:29|

1094|33217|4|1|229||||SECTION NO. 4|H1|0.0|||||11/11/2024 10:33:42|

1095|33218|4|1|229||||BILL NO. 1|H1|0.0|||||11/11/2024 10:33:52|

1096|33219|4|1|229||||FIRE PROTECTION|H1|0.0|||||11/11/2024 10:34:05|

1097|33220|4|1|229||||FIRE SERVICES|H2|0.0|||||11/11/2024 10:34:20|

1098|33221|4|1|229||||The Supply, delivery and installation of SABS approved material, accessories and equipment as specified.   |H3|0.0|||||18/11/2024 05:51:51|

1099|33222|4|1|229| A|||Fire Signage|SUM|3|||||18/11/2024 05:52:03|

1100|33223|4|1|229| B|||4.5/5kg Dry Chemical Fire Extinguisher, Including brackets to wall mount |EA|8|||||11/11/2024 10:34:21|

1101|33224|4|1|229| C|||890mm High x 590mm Width x 285mm Depth Fire Extinguishers Cabinet comes with Vandal Proof System|EA|8|||||18/11/2024 05:53:40|

1102|33225|4|1|229| D|||Emergence Evacuation Plan Design|EA|3|||||11/11/2024 10:34:21|

1103|33226|4|1|229||||SERVICING OF EXISTING FIRE HYDRANTS AND HORSE REELS|H2|0.0|||||11/11/2024 10:34:22|

1104|33227|4|1|229| E|||Servicing of exisiting fire Hydrant system |EA|6|||||11/11/2024 10:34:22|

1105|33228|4|1|229| F|||Servicing of existing fire horse reels system including required plumbing|EA|8|||||11/11/2024 10:34:22|

1106|33229|4|1|229| G|||Test  of the fire hydrant system|EA|3|||||11/11/2024 10:34:22|

1107|33230|4|1|229| H|||Issuing of Fire Compliance Certificate by a registered personal|EA|3|||||11/11/2024 10:34:22|

1108|0|4|1|||||||0.0|||||11/06/2025 12:00:00|

1109|33232|5|1|230||||SECTION NO. 5|H1|0.0|||||11/11/2024 10:35:47|

1110|33231|5|1|230||||BILL NO. 1|H1|0.0|||||11/11/2024 10:35:19|

1111|33233|5|1|230||||HVAC INSTALLATION|H1|0.0|||||11/11/2024 10:35:58|

1112|33234|5|1|230||||AIR CONDITION|H2|0.0|||||11/11/2024 10:36:37|

1113|33235|5|1|230||||Provide as per the client's specification and bring to working condition: Split type air conditioning units . The Units will operate on rotational basic as such will be programmed accordingly.|H3|0.0|||||11/11/2024 10:36:37|

1114|33236|5|1|230| A|||1.6kW Mid Wall Unit with 1.6 kW Outdoor unit inverter type Including wall mounted control panel, drainage pump, Air filter, decoration panel, mountings, connection to refrigerant piping and connection to drainage piping|EA|2|||||18/11/2024 05:54:21|

1115|33237|5|1|230| B|||1,6kW 4 Way Cassette  Unit with 1,6 kW Outdoor unit inverter type Including wall mounted control panel, drainage pump, Air filter, decoration panel, mountings, connection to refrigerant piping and connection to drainage piping|EA|3|||||11/11/2024 10:36:38|

1116|33238|5|1|230| C|||2,0kW 4 Way Cassette  Unit with 2,0 kW Outdoor unit inverter type Including wall mounted control panel, drainage pump, Air filter, decoration panel, mountings, connection to refrigerant piping and connection to drainage piping|EA|14|||||11/11/2024 10:36:39|

1117|33239|5|1|230| D|||3,0kW 4 Way Cassette  Unit with 3,0 kW Outdoor unit inverter type Including wall mounted control panel, drainage pump, Air filter, decoration panel, mountings, connection to refrigerant piping and connection to drainage piping|EA|4|||||11/11/2024 10:36:39|

1118|33240|5|1|230||||FANS UNIT|H2|0.0|||||11/11/2024 10:36:39|

1119|33241|5|1|231||||Provide as per the client's specification and bring to working condition fans units . The Units will operate on rotational basic as such will be programmed accordingly.|H3|0.0|||||11/11/2024 10:36:39|

1120|33242|5|1|231| A|||Waterproof In line axial supply fan (15[l/s] at 50 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|1|||||11/11/2024 10:36:39|

1121|33243|5|1|231| B|||Waterproof In line axial supply fan (27[l/s] at 100 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|1|||||11/11/2024 10:36:40|

1122|33244|5|1|231| C|||Waterproof In line axial supply fan (60[l/s] at 150 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|11|||||11/11/2024 10:36:40|

1123|33245|5|1|231| D|||Waterproof In line axial supply fan (72[l/s] at 150 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|2|||||11/11/2024 10:36:40|

1124|33266|5|1|231| E|||Waterproof In line axial supply fan (106[l/s] at 150 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|2|||||11/11/2024 11:03:39|

1125|33246|5|1|231| F|||Waterproof In line axial supply fan (109[l/s] at 150 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|3|||||11/11/2024 10:36:40|

1126|33265|5|1|231| G|||Waterproof In line axial supply fan (135[l/s] at 250 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|1|||||11/11/2024 11:03:16|

1127|33247|5|1|231| H|||Waterproof In line axial supply fan (150[l/s] at 250 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|1|||||11/11/2024 10:36:40|

1128|33248|5|1|231| J|||Waterproof In line axial supply fan (265[l/s] at 250 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|1|||||11/11/2024 10:36:40|

1129|33267|5|1|231| K|||Waterproof In line axial supply fan (398[l/s] at 250 [Pa])                                                                    Including mountings, sound attenuators and fitting to ducting as per specification document|EA|1|||||11/11/2024 11:05:02|

1130|33249|5|1|232||||DUCTING AND CONNECTIONS|H2|0.0|||||11/11/2024 10:36:40|

1131|33269|5|1|232| A|||Supply, delivery to site, storage and installation of the ducting system with accessories and sized in the drawing. Installation shall be in accordance with the manufacturer detailed design (Entrance Level)|SUM|1|||||11/11/2024 11:28:13|

1132|33250|5|1|232| B|||Supply, delivery to site, storage and installation of the ducting system with accessories and sized in the drawing. Installation shall be in accordance with the manufacturer detailed design (Quay and Upper Level)|SUM|2|||||11/11/2024 11:35:14|

1133|33251|5|1|232||||FRESH AIR SUPPLY AND EXTRACTION|H2|0.0|||||11/11/2024 10:36:41|

1134|33252|5|1|232| C|||Supply, delivery to site, storage and installation of the ducting system with accessories and sized in the drawing. Installation shall be in accordance with the manufacturer detailed design|SUM|3|||||11/11/2024 10:36:41|

1135|33253|5|1|232||||DAMPERS|H2|0.0|||||11/11/2024 10:36:41|

1136|33268|5|1|232| D|||Supply, delivery to site, storage and installation of the ducting system with accessories and sized in the drawing. Installation shall be in accordance with the manufacturer detailed design (Entrance Level)|SUM|1|||||11/11/2024 11:36:06|

1137|33254|5|1|232| E|||Supply, delivery to site, storage and installation of the ducting system with accessories and sized in the drawing. Installation shall be in accordance with the manufacturer detailed design (Quay and Upper Level)|SUM|2|||||11/11/2024 11:36:20|

1138|33255|5|1|232||||Diffusers, Louvers and Grills|H3|0.0|||||11/11/2024 10:36:42|

1139|33256|5|1|232| F|||Adjustable airflow round ceiling mounted diffuser - sized dia duct connection                                                                                                                  Including connection to ducting and fixing / replacing of roof tile|EA|24|||||11/11/2024 10:36:42|

1140|33257|5|1|232| G|||Issuing of COC by a registered personal|EA|3|||||11/11/2024 10:36:42|

1141|33258|5|1|232| H|||Testing and Commissioning of Installation|SUM|3|||||11/11/2024 10:36:42|

1142|0|5|1|||||||0.0|||||11/06/2025 12:00:00|

1143|33259|6|1|234||||SECTION NO. 6|H1|0.0|||||11/11/2024 10:37:28|

1144|33260|6|1|234||||BILL NO. 1|H1|0.0|||||11/11/2024 10:37:43|

1145|33261|6|1|234||||WET SERVICES INSTALLATION|H1|0.0|||||11/11/2024 10:38:29|

1146|33262|6|1|234||||WET SERVICES |H2|0.0|||||11/11/2024 10:39:02|

1147|33263|6|1|234||||The Supply, delivery and installation of SABS approved material, accessories and equipment as specified.   |H3|0.0|||||11/11/2024 10:39:03|

1148|33264|6|1|234| A|||PLUMBING - WATER SUPPLIES AND WATER CONNECTIONS|SUM|1|||||11/11/2024 10:39:03|

1149|0|6|1|||||||0.0|||||11/06/2025 12:00:00|

1150|7|7|1|235|1|200.1||STANDARD PRELIMINARIES|Page|136|0||||26/03/2002 01:45:41|

1151|14540|7|1|235|2|||BUILDERSWORK|Page|212|0||||03/05/2021 09:01:37|

1152|33041|7|1|235|3|||ELECTRICAL INSTALLATION|Page|228|0||||11/11/2024 08:50:52|

1153|33047|7|1|235|4|||FIRE PROTECTION INSTALLATION|Page|229|0||||11/11/2024 08:53:05|

1154|33049|7|1|235|5|||MECHANICAL INSTALLATION|Page|233|0||||11/11/2024 08:53:31|

1155|33051|7|1|235|6|||WET SERVICE INSTALLATION|Page|234|0||||11/11/2024 08:53:47|

1156|11|7|1|235||200||TOTAL OF BUILDING WORKS |ST|0.00||Sub Total|||20/07/2023 02:08:24|

1157|33281|7|1|235||234||CONTINGENCIES|H3|0.0|||||12/11/2024 10:37:38|

1158|33282|7|1|235||234||Allow the sum of 10% (ten percent) of the above Sub-Total for Contingencies to be expended as directed by the Employer or Employer's representative or deducted in whole or in part from the Contract Amount|TAX|10.00|||||12/11/2024 10:37:38|

1159|14|7|1|235||200||TOTAL OF BUILDING WORKS & CONTINGENCIES|ST|0.00||Sub Total|||20/07/2023 02:08:24|

1160|15|7|1|235||200||VALUE ADDED TAX at 15%|TAX|15.00|||||20/07/2023 02:08:24|
|*|TOTAL ITEMS|1160|MSD ITEMS|483|QUANTITY#|41387.30|RATE#|0.00|
|*|END|ASCII|
